Audit of Contractor Sample Clauses

Audit of Contractor. The TI Construction Contract shall provide that Landlord and Tenant shall have a right, within a reasonable period of time following Substantial Completion of Floor 32, to conduct an audit of the books and records of the TI Contractor to confirm the costs actually incurred with respect to the construction of the Floor 32 TI Work. The results of the audit shall be made available to both Landlord and Tenant. The TI Construction Contract shall provide for binding arbitration of all disputes arising over change orders or from the audit. Tenant shall be responsible for the costs of such audit and any arbitration relating thereto, subject to reimbursement from the TI Contractor as may be provided in the TI Construction Contract. Tenant shall be responsible for and entitled to any adjustments to the cost of the Floor 32 TI Work that may be made by reason of such audit.

Audit of Contractor. At any time during the life of this Contract, OGS Procurement Services reserves the right to suspend this Contract for failure of the Contractor to provide accurate and timely documentation as required by this Contract. This will include, but is not limited to submission of all reports, proof of insurance and Consultant Disclosure documents. OGS will activate this right for the failure of the Contractor to make timely and accurate payment of the quarterly Administrative Fee. This suspension will impact the Annual Contractor Evaluation. At any time during the life of this Contract, OGS Procurement Services reserves the right to audit the accuracy and timeliness of the Administrative Fee. Audits shall be conducted during regular business hours, upon not less than fifteen (15) business days prior written notice. Administrative Fees will be due immediately for any errors or omissions disclosed by any such audit. If, as a result of any such audit, Administrative Fees are determined to have been underpaid by more than five (5) percent (5%) for the period audited, Contractor shall pay the costs of such audit or three (3) times the discrepancy, whichever is higher. Failure to make such payments or repeated errors on subsequent audits may result in the scheduling of a responsibility meeting and may lead to termination of this Agreement. At any time during the life of this Contract, OGS Procurement Services reserves the right to audit the accuracy and timeliness of all payments and supporting documentation between Contractor, Subcontractors and Selected Candidates. Audits shall be conducted during regular business hours, upon not less than fifteen (15) business days prior written notice. Failure to comply or repeated errors on subsequent audits may result in the scheduling of a responsibility meeting and may lead to termination of this Agreement.

Audit of Contractor. Company shall have the right to audit Contractor's books and records relating to services performed hereunder. To facilitate such audit, Contractor shall retain its books and records made in any calendar year during the term of Agreement, for a period of two (2) years from the end of such calendar year. This obligation survives termination of this Agreement. For the purpose of audit, Company and its authorized representatives or agents shall have the right to examine during business hours at Contractor's office and for a reasonable length of time all books, records, accounts, correspondence, instructions, specification, maps, receipts and memoranda insofar as they are pertinent to this Agreement.

Audit of Contractor. The TI Construction Contract shall provide that Landlord and Tenant shall have a right, within a reasonable period of time following Substantial Completion of the Premises, to conduct an audit of the books and records of the Ti Contractor to confirm the costs actually incurred with respect to the construction of the TI Work, the allocation of costs between the Landlord’s Work and the TI Work and similar matters under the TI Construction Contract. The results of the audit shall be made available to both Landlord and Tenant. The TI Construction Contract shall provide for binding arbitration of all disputes arising over change orders or from the audit. Tenant shall be responsible for the costs of such audit and any arbitration relating thereto, subject to reimbursement from the TI Contractor as may be provided in the TI Construction Contract. Tenant shall be responsible for and entitled to any adjustments to the cost of the TI Work that may be made by reason of such audit. Landlord agrees that it will, at its sole cost and expense, apply for the permit and upon its receipt commence to remove the stairway between Floor 19 and Floor 20 and pursue the completion (with the exception of delays or conditions beyond the Landlord’s control) in accordance with Landlord’s or Landlord’s architect’s designs and plans

Audit of Contractor. The Company may at any time undertake, or engage a third party to undertake, an audit of the Contractor to ensure that: (a) the Contractor is compliant with the SHE Requirements; and (b) that the Contractor has ensured, and has proof, that all Contractor's Personnel are also compliant with the SHE Requirements.