Change of Scope Sample Clauses
A Change of Scope clause defines the process for modifying the original terms, deliverables, or requirements of an agreement. Typically, it outlines how either party can propose changes, the approval process for such changes, and any adjustments to timelines, costs, or responsibilities that may result. For example, if a client requests additional features in a project, this clause would govern how those requests are evaluated and incorporated. Its core function is to provide a structured method for handling changes, ensuring that both parties agree to and understand the implications of any modifications, thereby preventing disputes and maintaining project alignment.
POPULAR SAMPLE Copied 107 times
Change of Scope. (i) The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the Contractor to make modifications/ alterations to the Works (“Change of Scope”) within a period of six months counted from the Appointed Date. Upon the Authority making its intention known to the Contractor for the specific Change of Scope, be it positive or negative, the Contractor shall submit his proposal for the said Change of Scope involving additional cost or reduction in cost. Any such Change of Scope shall be made and valued in accordance with the provisions of this Article 13.
(ii) Provided that any such Change of Scope, excluding major structures (e.g. Major Bridge/ ROB/ RUB/ Flyover/ elevated road of more than 50 m length) may be required and agreed to be executed between the parties beyond the period of six months of the Appointed Date but before expiry of 50% of the original Scheduled Construction Period of the Project Highway, subject to the condition that it shall not entail any claims (e.g. Extension of Time/ Prolongation related claims), against the Authority.
(iii) The Change of Scope shall mean the following:
(a) change in specifications of any item of Works;
(b) omission of any work from the Scope of the Project except under Clause 8.3 (iii); provided that, subject to Clause 13.5, the Authority shall not omit any Work under this Clause in order to get it executed by any other authority; and / or
(c) any additional Work, Plant, Materials or services which are not included in the Scope of the Project, including any associated Tests on completion of construction.
Change of Scope. 13.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the Contractor to make modifications/alterations to the Works (“Change of Scope”) before the issue of the Completion Certificate either by giving an instruction or by requesting the Contractor to submit a proposal for Change of Scope involving additional cost or reduction in cost. Any such Change of Scope shall be made and valued in accordance with the provisions of this Article 13.
Change of Scope. 16.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works which are related and are necessary to the Bus Terminal and services which are not included in the Scope of the Project as contemplated by this Agreement (the “Change of Scope”). Any such Change of Scope shall be made in accordance with the provisions of this Article 16 and the costs thereof shall be expended by the Concessionaire and reimbursed to it by the Authority in accordance with Clause 16.3. The cost of change of scope of work shall not exceed 10% of total project cost.
16.1.2 If the Concessionaire determines at any time that a Change of Scope is necessary for providing safer and improved services to the passengers, it shall by notice in writing require the Authority to consider such Change of Scope. The Authority shall, within 15 (fifteen) days of receipt of such notice, either accept such Change of Scope with modifications, if any, and initiate proceedings therefor in accordance with this Article 16 or inform the Concessionaire in writing of its reasons for not accepting such Change of Scope.
16.1.3 Any works or services which are provided under and in accordance with this Article 16 shall form part of the Bus Terminal and the provisions of this Agreement shall apply mutatis mutandis to such works or services.
Change of Scope. 16.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, during the period of 10 (ten) years post COD of Bus Terminal, require the Concessionaire to carry out any additional works ("Additional Works"), which are related and are necessary to the Bus Terminal and services which are not included in the Scope of the Project as contemplated by this Agreement (the "Change of Scope"). Any such Change of Scope shall be made in accordance with the provisions of this Article 16 and the costs thereof shall be expended by the Concessionaire and reimbursed to it by the Authority in accordance with Clause
Change of Scope. The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the Contractor to make modifications/ alterations to the Works (“Change of Scope”) within a period of six months counted from the Appointed Date. Upon the Authority making its intention known to the Contractor for the specific Change of Scope, be it positive or negative, the Contractor shall submit his proposal for the said Change of Scope involving additional cost or reduction in cost. Any such Change of Scope shall be made and valued in accordance with the provisions of this Article 13.
Change of Scope. The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works and services which are not included in the Scope of the Project as contemplated by this Agreement (the "Change of Scope"). Any such Change of Scope shall be made in accordance with the provisions of this Article 16 and the costs thereof shall be expended by the Concessionaire and reimbursed to it by the Authority in accordance with Clause 16.3.
Change of Scope. 10.10.1. The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works and services which are not included in the scope of the Project as contemplated by this Agreement (“Change of Scope”). Provided no such Change of Scope shall be made in the Construction Period, if in the reasonable judgment of the Parties, it is likely to lead to delay in Project Completion or during the Operation Period, if in the reasonable judgement of the Parties, it is likely to have Material Adverse Effect on the provision of Services by the Concessionaire. The costs for carrying out required additional work as contemplated in Change of Scope shall be borne by the Authority.
10.10.2. In the event the Authority determines that a Change of Scope is necessary, it shall issue to the Concessionaire a notice specifying in reasonable detail the works and services contemplated thereunder (the “Change of Scope Notice”).
10.10.3. Upon receipt of a Change of Scope Notice, the Concessionaire shall, provide to the Authority, the following:
a.) Its estimation of the adverse impact, if any, which the Change of Scope is likely to have on the Construction Work or the Operation, as applicable; and
b.) The cost to be incurred by the Concessionaire for and in respect of such Change of Scope
10.10.4. Upon receipt of the information as per the Clause 10.10.3, the Authority shall, if it decides to proceed with the Change of Scope, convey its agreement or otherwise of the assessment of the Concessionaire. If the Concessionaire does not notify any adverse impact of a Change of Scope notified under the Change of Scope Notice within 30 (thirty) Days of the receipt thereof and/or the Authority does not disagree with the cost assessment of the Concessionaire, the Authority shall issue an order requiring the Concessionaire to proceed with the implementation of such Change of Scope. If an adverse impact is notified by the Concessionaire and / or the Authority disagrees with the cost assessment, the Parties shall in good faith modify the Change of Scope envisaged so as to remove the adverse impact/agree to the cost implication for carrying out the Change of Scope within a period of 30 (thirty) Days of notification of the adverse impact/cost. In the event that the Parties are unable to mutually agree to a Change of Scope and / or the cost of implementing the same, they may seek intervention of the IE&A to resolve the differences and upon the fin...
Change of Scope. 16.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works and services which are not included in the Scope of the Project as contemplated by this Agreement (the “Change of Scope”). Any such Change of Scope shall be made in accordance with the provisions of this Article 16 and the costs thereof shall be expended by the Concessionaire and reimbursed to it by the Authority in accordance with Clause 16.3.
16.1.2 If the Concessionaire determines at any time that a Change of Scope is necessary for providing safer and improved services to the Users, it shall by notice in writing require the Authority to consider such Change of Scope. The Authority shall, within 15 (fifteen) days of receipt of such notice, either accept such Change of Scope with modifications, if any, and initiate proceedings therefor in accordance with this Article 16 or inform the Concessionaire in writing of its reasons for not accepting such Change of Scope, which decision of the Authority shall be final and binding.
16.1.3 Any works or services which are provided under and in accordance with this Article 16 shall form part of the Project and the provisions of this Agreement shall apply mutatis mutandis to such works or services.
Change of Scope. 16.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works and services which are not included in the Scope of the Project as contemplated by this Agreement (the “Change of Scope”). Any such Change of Scope shall be made in accordance with the provisions of this Article 16 and the costs thereof shall be expended by the Concessionaire and reimbursed to it by the Authority in accordance with Clause 16.3.
16.1.2 Any works or services which are provided under and in accordance with this Article 16 shall form part of the Hospital and the provisions of this Agreement shall apply mutatis mutandis to such works or services.
Change of Scope. 17.1.1. The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works and services which are not included in the Project as contemplated by this Agreement (the “Change of Scope”). Any such Change of Scope shall be made in accordance with the provisions of this Article 17 and the costs thereof shall be expended by the Concessionaire and reimbursed to it by the Authority in accordance with Clause 17.3.
17.1.2. If the Concessionaire determines at any time that a Change of Scope is necessary for providing safer and improved Healthcare Services, it shall by notice in writing require the Authority to consider such Change of Scope. The Authority shall, within [15 (fifteen)] days of receipt of such notice, either accept such Change of Scope with modifications, if any, and initiate proceedings therefore in accordance with this Article 17 or inform the Concessionaire in writing of its reasons for not accepting such Change of Scope.