Complex Alterations Clause Samples

POPULAR SAMPLE Copied 1 times
Complex Alterations. If the nature, volume or complexity of any proposed Alterations, causes Landlord to consult with an independent architect, engineer or other consultant, Tenant will reimburse Landlord for the fees and expenses incurred by Landlord. If any improvements will affect the basic heat, ventilation and air conditioning or other Building systems or the Building, Landlord may require that such work be designed by consultants designated by Landlord and be performed by Landlord or Landlord’s contractors.
View SourceView Similar (13)
Complex Alterations. If the nature, volume or complexity of any proposed alteration, addition, improvement or installation causes Lessor to consult with an independent architect, engineer or other consultant, L▇▇▇▇▇ will reimburse Lessor for the fees and expenses incurred by L▇▇▇▇▇. If any improvements will affect the Building Common Areas, Lessor may require that such work be designed by consultants designated by L▇▇▇▇▇ and be performed by Lessor or Lessor’s contractors at Lessee’s expense.
View SourceView Similar (4)
Complex Alterations. If the nature, volume or complexity of any proposed Alteration will affect the basic heat, ventilation and air conditioning or other Building Facilities or systems or the Building, Tenant shall furnish to Landlord information, including, without limitation, construction plans and consultant’s reports, required by Landlord to assure Landlord that the Alterations do not adversely affect the Building or Building Facilities or systems; otherwise, Landlord may (i) withhold its consent for the Alteration; or (ii) require that the work be designed by consultants designated by Landlord and/or be performed by Landlord or Landlord’s contractors.
View SourceView Similar (3)
Complex Alterations. If the nature, volume or complexity of any proposed Alterations, causes Landlord to consult with an independent architect, engineer or other consultant, ▇▇▇▇▇▇ will reimburse Landlord for the reasonable fees and expenses incurred by Landlord, such fees not to exceed five hundred dollars ($500.00). If any improvements will affect the basic heat, ventilation and air conditioning or other Building systems or the Building, Landlord may require that such work be designed by consultants reasonably designated by Landlord and be performed by Landlord or Landlord’s contractors.
View SourceView Similar (2)
Complex Alterations. Tenant shall seek Landlord's approval, which approval shall not be unreasonably withheld, delayed or conditioned, of Tenant's architects and engineers who design any Alteration which by the nature of its volume or complexity may adversely affect the Shell Improvements. If ▇▇▇▇▇▇'s architect or engineer is not approved by Landlord, for any such Alteration, Tenant may nevertheless employ such architect or engineer for such purpose, and Landlord within Landlord's reasonable judgment, may consult with an independent architect, engineer, or other consultant with respect to such alteration and Tenant will reimburse Landlord for the reasonable fees and expenses incurred by Landlord. If any Alteration will affect the basic mechanical, electrical, or plumbing systems of the Improvements, Landlord may require that the work be reviewed by consultants designated by Landlord at Tenant's reasonable expense.
View Source
Complex Alterations. If the nature, volume or complexity of any proposed Alteration will affect the basic heat, ventilation and air conditioning or other Building Facilities or systems or the Building. Tenant shall furnish to Landlord Information reasonably required by Landlord to insure Landlord that the Alterations meet Landlord's reasonable requirements so as not to adversely affect the Building or Building Facilities or systems; otherwise. Landlord may require that the work be designed by consultants designated by Landlord and be performed by Landlord or Landlord's contractors. Any work described in this Section 6.5(a) must be approved as determined in Landlord's sole discretion, which will not be reasonably withheld.
View Source

Related to Complex Alterations

  • Alterations Tenant shall not alter or add to any part of the Demised Premises except with Landlord's prior consent which consent shall not be unreasonably withheld or delayed. Tenant shall make all alterations and additions to the Demised Premises at its own risk and cost and in accordance with all applicable laws, and shall indemnify Landlord against all expenses, liens, claims, or damages to either persons or property or to the Demised Premises arising out of or resulting from such alterations or additions. All alterations and additions shall be subject to the approval of Landlord which shall not be unreasonably withheld or delayed and shall remain after the termination of this Lease for the benefit of Landlord unless otherwise provided in said consent. No alterations or additions to the Demised Premises shall be made unless Tenant uses a general contractor reasonably approved by Landlord. Notwithstanding the foregoing, (a)(i) the freight elevator shall not be overloaded beyond the factory certified limits, (ii) any damage to the elevator shall be repaired at Tenant's expense, and (iii) Tenant agrees to use Landlord's current contractor for installation, maintenance, and repairs to the freight elevator; and (b) no modification of the electrical, HVAC, plumbing, fire sprinkler, fire control and suppression systems (halon), and building automation systems of the Demised Premises shall be permitted without Landlord's prior written consent and Landlord's approval of the contractor.

  • Tenant Alterations Tenant will not make or allow to be made any alterations in or to the Premises without first obtaining the written consent of Landlord, which consent may be granted or withheld in Landlord’s sole discretion; provided, however that such Landlord consent shall not be required for changes that are not to the exterior, or are not to the structure, or are not to Buildings systems, or which are merely cosmetic in nature. All Tenant alterations will be accomplished in a good and workmanlike manner at Tenant’s sole expense, in conformity with all Applicable Laws by a licensed and bonded contractor approved in advance by Landlord, such approval of contractor not to be unreasonably withheld or delayed. All contractors performing alterations in the Premises shall carry workers’ compensation insurance, commercial general liability insurance, automobile insurance and excess liability insurance in amounts reasonably acceptable to Landlord and shall deliver a certificate of insurance evidencing such coverages to Landlord prior to commencing work in the Premises. Upon completion of any such work, Tenant shall provide Landlord with “as built” plans, copies of all construction contracts, and proof of payment for all labor and materials. All alterations or improvements, shall remain with the Premises upon Lease termination or expiration and will be surrendered to Landlord along with the Premises at such time and will be deemed owned by Landlord at all times from and after and upon completion thereof (but rights to the use of same and Tenant’s obligations to keep in good order, condition and repair and maintain same, as a part of the Premises, shall remain with Tenant pursuant to this Lease during the term of this Lease). Tenant will have no authority or power, express or implied, to create or cause any construction lien or mechanics’ or materialmen’s lien or claim of any kind against the Premises, the Property or any portion thereof. Landlord’s interest in the Premises is not and shall not be subject to any liens as a result of Tenant’s use or occupancy of the Premises including specifically, without limitation, for improvements made by Tenant, and all such liens are expressly prohibited. Tenant will promptly cause any such liens or claims to be released by payment, bonding or otherwise within thirty (30) days after request by Landlord, and will indemnify Landlord against losses arising out of any such claim including, without limitation, legal fees and court costs. Landlord has the right, but not the obligation, to discharge any such lien. Any amount paid by Landlord for such purpose and Landlord’s related reasonable attorneys’ fees shall be paid by Tenant to Landlord upon demand and shall accrue interest from the date paid by Landlord until Landlord is reimbursed therefor at the highest rate permitted by Law. NOTICE IS HEREBY GIVEN THAT LANDLORD WILL NOT BE LIABLE FOR ANY LABOR, SERVICES OR MATERIAL FURNISHED OR TO BE FURNISHED TO TENANT, OR TO ANYONE HOLDING THE PREMISES THROUGH OR UNDER TENANT, AND THAT NO MECHANICS’ OR OTHER LIENS FOR ANY SUCH LABOR, SERVICES OR MATERIALS WILL ATTACH TO OR AFFECT THE INTEREST OF LANDLORD IN THE PREMISES. TENANT WILL DISCLOSE THE FOREGOING PROVISIONS TO ANY CONTRACTOR ENGAGED BY TENANT PROVIDING LABOR, SERVICES OR MATERIAL TO THE PREMISES.

  • LEASE ALTERATIONS The Owner hereby gives power to the Agent to initiate, sign, renew, modify, or cancel rental agreements and leases for the Property, or any part thereof and collect and give receipts for rents, other fees, charges, and security deposits.

  • Tenant’s Alterations Tenant will not cut or drill into or secure any fixture, apparatus or equipment or make alterations, improvements or physical additions (collectively, “Alterations”) of any kind to any part of the Premises without first obtaining the written consent of Landlord, such consent not to be unreasonably withheld. Alterations shall, at ▇▇▇▇▇▇▇▇’s option, be done by Landlord at Tenant’s sole cost and expense. Landlord’s consent shall not be required for (i) the installation of any office equipment including internal partitions which do not require disturbance of any structural elements or systems within the Building or (ii) minor work, including decorations, which does not require disturbance of any structural elements or systems within the Building and which costs in the aggregate less than $5,000. If no approval is required or if Landlord approves Tenant’s Alterations and agrees to permit ▇▇▇▇▇▇’s contractors to do the work, Tenant, prior to the commencement of labor or supply of any materials, must furnish to Landlord (i) a duplicate or original policy or certificates of insurance evidencing (a) general public liability insurance for personal injury and property damage in the minimum amount of $3,000,000.00 combined single limit, (b) statutory ▇▇▇▇▇▇▇’▇ compensation insurance, and (c) employer’s liability insurance from each contractor to be employed (all such policies shall be non-cancelable without thirty (30) days prior written notice to Landlord and shall be in amounts and with companies satisfactory to Landlord); (ii) construction documents prepared and sealed by a registered Pennsylvania architect if such alteration causes the aggregate of all Alterations to be in excess of $10,000; (iii) all applicable building permits required by law; and (iv) an executed, effective Waiver of Mechanics Liens from such contractors and all sub-contractors in states allowing for such waivers or the cost of such alteration must be bonded by ▇▇▇▇▇▇. Any approval by Landlord permitting Tenant to do any or cause any work to be done in or about the Premises shall be and hereby is conditioned upon ▇▇▇▇▇▇’s work being performed by workmen and mechanics working in harmony and not interfering with labor employed by Landlord, ▇▇▇▇▇▇▇▇’s mechanics or their contractors or by any other tenant or their contractors. If at any time any of the workmen or mechanics performing any of Tenant’s work shall be unable to work in harmony or shall interfere with any labor employed by Landlord, other tenants or their respective mechanics and contractors, then the permission granted by Landlord to Tenant permitting Tenant to do or cause any work to be done in or about the Premises, may be withdrawn by Landlord upon forty-eight (48) hours written notice to Tenant. All Alterations (whether temporary or permanent in character) made in or upon the Premises, either by Landlord or Tenant, shall be Landlord’s property upon installation and shall remain on the Premises without compensation to Tenant unless Landlord provides written notice to Tenant to remove same at the expiration of the Lease, in which event Tenant shall promptly remove such Alterations and restore the Premises to good order and condition. At Lease termination, all furniture, movable trade fixtures and equipment (including telephone, security and communication equipment system wiring and cabling) shall, at Landlord’s option, be removed by Tenant and shall be accomplished in a good and workmanlike manner so as not to damage the Premises or Building and in such manner so as not to disturb other tenants in the Building. All such installations, removals and restoration shall be accomplished in a good and workmanlike manner so as not to damage the Premises or Building and in such manner so as not to disturb other tenants in the Building. If Tenant fails to remove any items required to be removed pursuant to this Article, Landlord may do so and the reasonable costs and expenses thereof shall be deemed Additional Rent hereunder and shall be reimbursed by Tenant to Landlord within fifteen (15) business days of Tenant’s receipt of an invoice therefor from Landlord.

  • Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter: a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications). b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows: (i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and (ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ of ▇▇▇▇▇ ▇▇▇▇ LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises. c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.