CPM Schedule Sample Clauses
POPULAR SAMPLE Copied 6 times
CPM Schedule. Contractor shall produce a CPM Schedule in accordance with Section 5.4 of the Agreement that will be the reference schedule for the duration of the Project unless revised by Change Order approved by the Owner. The CPM Schedule shall be the Project baseline plan comprising a control network detailing all activities to be completed in a logical sequence and being in sufficient detail to identify key activities and restraints, interdependencies, interrelationships and resources required to control the Project. The CPM Schedule shall:
a. Be consistent with the Project Schedule, including LNTP, NTP, the Guaranteed Substantial Completion Date for each Subproject;
b. Represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Project Schedule;
c. Be a detailed graphic representation of all significant aspects of the Work showing Contractor’s plans for performance of the Work;
d. Comply with GECP;
e. Indicate a level of detail sufficient for Contractor to plan, organize, direct, coordinate, perform and execute the Work, and for Owner to monitor the progress of the Work;
f. Include separate activities for each significant portion of the Work including activities for mobilization, engineering, procurement, construction, commissioning, start up, testing, closeout and demobilization;
g. Show the duration, start dates, and finish dates for each activity;
h. Show activity number, activity description, and responsible Person (i.e., Contractor, Subcontractor, or Sub-subcontractor) for each activity;
i. Reflect logical relationships between activities with a reasonable duration for each activity, and show an uninterrupted critical path from the LNTP through NTP, First LNG Cargo, Substantial Completion of each Subproject and Final Completion of each Subproject;
j. Indicate all Milestones to be used for progress payments. The initial CPM Schedule shall reflect the dates on the original Milestones progress payment schedule. Thereafter, at least once each quarter Milestones shall be re-scheduled in the CPM Schedule, if necessary, to reflect the current Schedule progress and updated projected Milestone dates. New Change Order Milestones, if any, shall be incorporated into the CPM Schedule at the quarterly CPM Schedule update; and
k. Be segregated into two or more schedule sub-networks defining: (1) Work within the Liquefaction Site and (2) Work within Existing Facilities as generally defined in Attachment X. The Existing Facilities sub-netwo...
CPM Schedule. Prior to commencement of the Construction Phase Services and concurrently with submission of the GMP Proposal, the CM shall submit an up-to-date CPM Schedule for the performance of Construction Phase Services as specified that is consistent with and meets the Contract Time Requirements and the Owner’s Project Schedule requirements and provides for the expeditious and practicable execution of the Work. The CPM Schedule shall include reasonable periods of time for the Owner’s and A/E’s review and approval of shop drawings and submissions and for the approval of other authorities having jurisdiction over the Project. When the CM’s initial CPM Schedule is approved by the ODR in connection with the GMP approval process, this updated schedule will become a part of the GMP Agreement that will be incorporated into this Agreement and shall become the baseline for evaluating performance of the CM. The CM shall monitor the progress of the Work in relation to the CPM Schedule and the Contract Time Requirements and the Owner’s Project Schedule requirements and shall provide the Owner with at least monthly updates and status reports as required by the Contract Documents. The initial CPM Schedule shall be revised in accordance with the Work Progress Schedule requirements of the UGC at appropriate intervals as required by the conditions of the Work and Project to reflect the current status of completed or in-progress activities, with thorough updates to such Schedule prepared at least monthly and furnished to Owner upon request. The time periods established by the Contract Time Requirements and the Owner’s Project Schedule requirements shall not be changed without the written consent from the Owner. Whenever significant changes to the Project
CPM Schedule. Prior to commencement of construction, the Contractor shall submit an up- to-date CPM Schedule for the performance of construction services as specified. The CPM Schedule shall include reasonable periods of time for the Owner’s and A-E’s review and approval of shop drawing submissions and for the approval of other authorities having jurisdiction over the Project. The Contractor shall monitor the progress of the Project in relation to the CPM Schedule and provide the Owner with at least monthly updates and status reports as required by the Contract Documents. The time periods established in the CPM Schedule and the overall duration of the Project and shall not be changed without the written consent from the Owner. Modifications to the CPM Schedule logic, coding, layouts and filters, detail, and activity durations shall be in accordance with any scheduling requirements set forth in the Contract Documents or as otherwise approved by the Owner.
CPM Schedule. As of the date of this Agreement, the parties have agreed to the CPM Schedule attached hereto as Exhibit L. Prior to commencement of the Construction Phase Services and concurrently with submission of the Guaranteed Maximum Price Proposal, the CM shall submit an updated CPM Schedule for the performance of Construction Phase Services as specified. The CPM Schedule shall include reasonable periods of time for the Owner’s and A/E’s review and approval of shop drawings and submissions and for the approval of other authorities having jurisdiction over the Project. When approved by the ODR in connection with the GMP approval process, this updated schedule will become a part of the GMP agreement that will be incorporated into this Contract by Change Order.
CPM Schedule. CM@RISK shall submit to CITY, on or before the effective date of the Construction Contract, a Construction Progress Schedule in Critical Path Method (CPM) format indicating the times for starting and completing the various stages of the Work, including any Milestones specified in this Contract and as more fully described in the General Conditions and other Contract Documents. Revisions/updates to the CPM schedule shall be submitted as often as necessary to accurately reflect plans for completion of the work, but no less frequently than required in the Contract Documents.
CPM Schedule. Attached hereto as Exhibit D-2, is the Contractor’s initial CPM Schedule for the performance of construction services that is consistent with and meets the Contract Time Requirements and the Owner’s Project Schedule requirements and provides for the expeditious and practicable execution of the Work. The CPM Schedule shall include reasonable periods of time for the Owner’s and A/E’s review and approval of shop drawings and submissions and for the approval of other authorities having jurisdiction over the Project. The Contractor’s initial CPM Schedule attached as Exhibit D-2 shall become the baseline for evaluating performance of the Contractor. The Contractor shall monitor the progress of the Work in relation to the CPM Schedule and the Contract Time Requirements and the Owner’s Project Schedule requirements and shall provide the Owner with at least monthly updates and status reports as required by the Contract Documents. The CPM Schedule shall be revised in accordance with the Work Progress Schedule requirements of the UGC at appropriate intervals as required by the conditions of the Work and Project to reflect the current status of completed or in-progress activities, with thorough updates to the CPM Schedule prepared at least monthly and furnished to Owner upon request. The time periods established by the Contract Time Requirements and the Owner’s Project Schedule requirements shall not be changed without the written consent from the Owner. Whenever significant changes to the Project approved by the Owner do occur, such as added or deleted activities, must be reflected on an updated CPM Schedule to be submitted to Owner. However, any modifications to the CPM Schedule logic, coding, layouts and filters, detail, and activity durations shall be in accordance with any scheduling requirements set forth in the Contract Documents or as otherwise approved by the Owner.
CPM Schedule. Within ninety (90) days of the award of this Agreement, Construction Manager shall submit a detailed Project Schedule in CPM format, which includes the Milestones set forth in Section 6.4, and which will indicate a start date for the Work approved by Owner. The Project Schedule shall be subject to review and approval by Owner. Upon approval, the Project Schedule shall be attached hereto as Exhibit C, and shall serve as the baseline schedule for the remainder of the Project.
CPM Schedule. No later than thirty (30) Days after the Effective Date, Contractor shall prepare and submit to Owner for Owner’s review and approval, not to be unreasonably withheld: (i) a detailed level 3 resource/man-hour loaded critical path method schedule for the Work using the latest version of Primavera Project Planner (“Primavera Project Planner”) and meeting all requirements of this Section 5.4A (such schedule, once approved by Owner, is hereinafter referred to as the “CPM Schedule”) and (ii) a detailed resource plan generated by the CPM Schedule and developed in accordance with Attachment B and Attachment X. Such submission to Owner of the CPM Schedule shall be in hard copy and native electronic format. The CPM Schedule shall be consistent with the Key Dates and shall represent Contractor’s best judgment as to how it shall complete the Work in compliance with the Guaranteed Dates. The CPM Schedule shall, at a minimum, be detailed at a level 3 (with each activity containing Work for on discipline or craft having a maximum duration of twenty (20) Days, except in limited circumstances when, due to the nature of the activity, a longer duration is necessary) for all activities for the Facility (including engineering, procurement, prefabrication or pre-assembly prior to erection, delivery of equipment, construction, required Owner or government agency inspections, procurement of Contractor permits, construction, pre-commissioning, Commissioning, testing and startup) and shall comply with GECP. Without limitation of the foregoing, the CPM Schedule shall: (i) show the duration, early/late start dates, early/late finish dates and available total float value for each activity, show a unique activity number, activity description, actual start/finish dates, remaining duration, physical percent complete and reflect logical relationships between activities, show an uninterrupted critical path from NTP through each of the Key Dates including Substantial Completion of each Train and Final Completion of the Facility; (ii) be tagged by activity codes to allow sorting and filtering by responsible Contractor, Subcontractor, Sub-subcontractor, Owner activities, discipline, craft, major work area, engineering, procurement, construction and commissioning (iii) the Work Breakdown Structure identifier shall be included for each activity, and (iv) be man-hour loaded to reflect the projected manpower to be used per activity (whether provided by Contractor or any Subcontractor or Sub-subc...
CPM Schedule. Attached hereto as Exhibit D-2, is the Contractor’s initial CPM Schedule for the performance of construction services that is consistent with and meets the Contract Time Requirements and the Owner’s Project Schedule requirements and provides for the expeditious and practicable execution of the Work. The CPM Schedule shall include reasonable periods of time for the Owner’s and A/E’s review and approval of shop drawings and submissions and for the approval of other authorities having jurisdiction over the Project. The Contractor’s initial CPM Schedule attached as Exhibit D-2 shall become the baseline for evaluating performance of the Contractor. The Contractor shall monitor the progress of the Work in relation to the CPM Schedule and the Contract Time Requirements and the Owner’s Project Schedule requirements and shall provide the Owner with at least monthly updates and status reports as required by the Contract Documents. The CPM Schedule shall be revised in accordance with the Work Progress Schedule requirements of the UGC at appropriate intervals as required by the conditions of the Work and Project to reflect the
CPM Schedule. Prior to commencement of the Construction Phase Services and concurrently with submission of the GMP Proposal, the CM shall submit an up-to-date CPM Schedule for the performance of Construction Phase Services as specified. The CPM Schedule shall include reasonable periods of time for the Owner’s and A/E’s review and approval of shop drawings and