Implementation Delays Sample Clauses

POPULAR SAMPLE Copied 5 times
Implementation Delays. In the event Delivery of CGM Software has not commenced after ninety (90) calendar days after the Effective Date of this Agreement, You agree CGM may, in its sole and absolute discretion, either invoice or charge your credit card or another method of Direct Payment, a fee of One Thousand Dollars ($1,000) for each month Delivery of CGM of Software has not commenced. CGM may also elect to charge You the full installation amount as well as start charging You any recurring fees.
View Source
Implementation Delays. Subject to the further terms of this Section, if MetroPCS reasonably determines that Supplier is likely to fail to timely complete a Critical Milestone, then at MetroPCS’ request and, unless the terms of subsection (f) below apply, *** to MetroPCS, Supplier shall provide that number and type of additional Supplier Personnel as may be required or necessary to complete the Critical Milestone by its completion date. If Supplier already has failed to timely complete a Critical Milestone, then without limiting any other available rights and remedies: (a) MetroPCS shall have the right to *** under the applicable Purchase Order; (b) at MetroPCS’ request and, unless the terms of subsection (f) below apply, *** Supplier shall provide that number and type of additional Supplier Personnel as may be required or necessary to complete the Critical Milestone within a re-adjusted time frame established by MetroPCS, provided that: (i) any adjustment of a Critical Milestone date shall not operate to adjust any future Critical Milestone date (unless specifically agreed to in writing by MetroPCS); and (ii) notwithstanding any such adjustment, MetroPCS shall be entitled to *** (“Delay Credits”) based on the original Critical Milestone date (unless specifically waived in writing by MetroPCS); and (c) MetroPCS shall receive ***. Notwithstanding the foregoing, if a Critical Milestone has been delayed (each of the following events constitutes an “Excuse”): (d) *** due to the occurrence of a Force Majeure Event; (e) by mutual written agreement of the parties; or (f) as a *** result of MetroPCS’ *** failure to perform *** obligations under the Agreement and designated as a MetroPCS obligation, provided that such failure and its likely impact on Supplier’s ability to timely achieve the Critical Milestone timely was identified sufficiently in advance by Supplier in a status report or other written notice to MetroPCS, the Critical Milestone date and any other subsequent affected Critical Milestone date(s) directly affected by such MetroPCS delay shall be extended automatically *** to account for the period of delay directly caused by the Excuse.
View Source
Implementation Delays 
View Source

Related to Implementation Delays

  • Project Implementation The Borrower shall:

  • Project Implementation Manual The Recipient, through the PCU, shall: (i) take all action required to carry out Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4 (ii) of the Project in accordance with the provisions and requirements set forth or referred to in the Project Implementation Manual; (ii) submit recommendations to the Association for its consideration for changes and updates of the Project Implementation Manual as they may become necessary or advisable during Project implementation in order to achieve the objective of Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4(ii) of the Project; and (iii) not assign, amend, abrogate or waive the Project Implementation Manual or any of its provisions without the Association’s prior agreement. Notwithstanding the foregoing, if any of the provisions of the Project Implementation Manual is inconsistent with the provisions of this Agreement, the provisions of this Agreement shall prevail and govern.

  • Implementation Services Vendor shall provide the Implementation Services, if any, described in Exhibit A. The Services Fees for any Implementation Services shall be described in Exhibit A.

  • Implementation Plan The Authority shall cause to be prepared an Implementation Plan meeting the requirements of Public Utilities Code Section 366.2 and any applicable Public Utilities Commission regulations as soon after the Effective Date as reasonably practicable. The Implementation Plan shall not be filed with the Public Utilities Commission until it is approved by the Board in the manner provided by Section 4.9.

  • COOPERATION IN IMPLEMENTATION On demand of the other Spouse and without undue delay or expense, each Spouse shall execute, acknowledge, or deliver any instrument, furnish any information, or perform any other acts reasonably necessary to carry out the provisions of this Agreement. If a Spouse fails to execute any document as required by this provision, the court may appoint the court clerk or his or her authorized designee to execute the document on that ▇▇▇▇▇▇’s behalf.