Inspection and Acceptance of Construction Sample Clauses

The 'Inspection and Acceptance of Construction' clause establishes the process by which completed construction work is reviewed and formally approved by the client or their representative. Typically, this clause outlines the right of the client to inspect the work at various stages and upon completion, and may specify procedures for notifying the contractor of any defects or non-conformities that must be remedied before final acceptance. Its core practical function is to ensure that the finished construction meets the agreed-upon standards and specifications before the client assumes ownership or makes final payment, thereby protecting the client from substandard work and clarifying the criteria for project completion.
Inspection and Acceptance of Construction. A. The Contractor will maintain an adequate inspection system and perform such inspections as will ensure that the Work completed conforms to the Work Specification. All Work is subject to Owner and City inspection and testing at places and at reasonable times before Acceptance to ensure strict compliance with the Contract Documents. B. The Contractor will, without charge, replace or correct Work found by the City not to conform to the Work Specifications or quality standards acceptable to the City of Plano. The Contractor will promptly segregate and remove rejected material from the Work site. C. If the Contractor does not promptly replace or correct rejected Work, the City may withhold payment or terminate for default per the conditions set herein. D. The Contractor will notify the City, as to the date when in its opinion all or a designated portion of the Work will be completed and ready for inspection. Acceptance will be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Owner's right under any warranty or guarantee.
View Source
Inspection and Acceptance of Construction. 2.3.1. The Grantee shall be responsible for inspection and acceptance of the work of its construction contractor(s). 2.3.2. The FINAL PROJECT INSPECTION REPORT (NGB Form 593) shall be completed and certified by the USPFO upon all the bills being paid and any outstanding claims settled. 2.3.3. Final payment reimbursement to the state shall be granted after the NGB Form 593 has been completed. 2.3.4. Upon the USPFO's certification of final acceptance, the project shall be considered complete.
View Source
Inspection and Acceptance of Construction. 2.4.1. The City of Madison shall be responsible for inspection and acceptance of the work by its construction contractor. ANG shall not issue directions to any City of Madison contractor and shall communicate with a City of Madison contractor only through, or with the permission of, an authorized City of Madison representative. 2.4.2. Upon the USPFO’s concurrence with final acceptance, the project shall be considered complete. 2.4.3. Final payment to the City of Madison shall be after the final Project Inspection Report has been completed and then approved by the USPFO. The following format will be used in making this report: Project: XGFG092030, Drainage Ditch 1. State: Wisconsin City: Madison 2. Date: Percent Completed: 3. Contracting Officer: 4. Contractor: 5. Contract No: Amount: 6. Base: ▇▇▇ ▇▇, ▇▇▇▇▇ ▇▇▇▇▇, Madison, WI This is to certify that [Company], contractor, completed on [date] all work under Contract No. [contract number] dated [contract date] for Project XGFG092030, Drainage Ditch, at ▇▇▇▇▇ Field, Madison, WI; that final inspection of the work was accomplished by the undersigned on [date]; that the materials and labor were furnished in accordance with the terms of the specifications and contract; that all required guarantees have been furnished; that the work was performed in accordance with approved specifications and/or contract drawings as modified by approved change orders and supplemental agreements with no exception; and that all work under this contract was completed on [date]. [Project Inspector] The work completed under this contract is hereby accepted for the Government as of [date]. [Contracting Officer]
View Source
Inspection and Acceptance of Construction 
View SourceView Similar (3)

Related to Inspection and Acceptance of Construction

  • ADDITIONAL CONSTRUCTIONS The Promoter undertakes that it has no right to make additions or to put up additional structure(s) anywhere in the Project after the building plan has been approved by the competent authority(ies) except for as provided in the Act.

  • Inspection of construction records The Authority shall have the right to inspect the records of the Contractor relating to the Works.

  • Commencement and Completion of Construction Subject to Unavoidable Delays, Developer shall cause construction of the Minimum Improvements to be undertaken and completed: (i) by no later than June 1, 2020; or (ii) by such other date as the parties shall mutually agree upon in writing. Time lost as a result of Unavoidable Delays shall be added to extend this date by a number of days equal to the number of days lost as a result of Unavoidable Delays. All work with respect to the Minimum Improvements shall be in conformity with the Construction Plans approved by the building official or any amendments thereto as may be approved by the building official. Developer agrees that it shall permit designated representatives of the City, upon reasonable notice (which does not have to be written), to enter upon the Development Property during the construction of the Minimum Improvements to inspect such construction and the progress thereof.

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

  • DAF Construction The DAF shall be designed and constructed in accordance with Good Utility Practice. Within one hundred twenty (120) Calendar Days after the Commercial Operation Date, unless the Developer and Connecting Transmission Owner agree on another mutually acceptable deadline, the Developer shall deliver to the Connecting Transmission Owner and NYISO “as- built” drawings, information and documents for the DAF, such as: a one-line diagram, a site plan showing the Large Generating Facility and the DAF, plan and elevation drawings showing the layout of the DAF, a relay functional diagram, relaying AC and DC schematic wiring diagrams and relay settings for all facilities associated with the Developer’s step-up transformers, the facilities connecting the Large Generating Facility to the step-up transformers and the DAF, and the impedances (determined by factory tests) for the associated step-up transformers and the Large Generating Facility. The Developer shall provide to, and coordinate with, Connecting Transmission Owner and NYISO with respect to proposed specifications for the excitation system, automatic voltage regulator, Large Generating Facility control and protection settings, transformer tap settings, and communications, if applicable.