KEY INFORMATION TABLE Clause Samples
The Key Information Table clause serves to summarize and present the most important terms and details of an agreement in a clear, easily accessible format. Typically, this table appears at the beginning of a contract and includes essential information such as parties' names, effective dates, payment terms, and key obligations. By consolidating critical data in one place, the clause helps parties quickly reference and understand the main points of the contract, reducing the risk of misunderstandings and ensuring clarity.
KEY INFORMATION TABLE. Commercial Information Subject Clause Key information
KEY INFORMATION TABLE. Commercial Information Subject Clause Key Information
(a) [the modules, support structures, inverters, transformers, switchgear, SCADA System, monitoring and site surveillance system, the Spares Stock (if applicable) and all other equipment required for the Facility, save to the extent any of this equipment and materials forms part of the Balance of Plant]. PV System Delivery Point 4.14(b) [●]2 Scheduled Equipment Acceptance Date 4.14(b) [●] Lender's Performance Standards3 5.1 [insert required performance standards of the Lender e.g. "Equator Principles" and/or "IFC Performance Standards" or][Not applicable]. Industry Standards 5.4(b) [IEC standard 62446 (Photovoltaic (PV) systems - requirements for testing, documentation and maintenance)]. Defects Warranty Period 11.2(a) [●] commencing on the Commercial Operation Date as may be extended in accordance with this Agreement. Modules Breakage Threshold 11.2(b) [insert number or percentage of Modules]. Scheduled COD 12.2 [●] Delay Liquidated Damages Rate 12.3 [●] per day of delay. Delay Liquidated Damages Cap4 12.4 [●] Commercial Operation Longstop Date 12.5 [●] Minimum Guaranteed Capacity 15.2 [●] Default Rate 23.1(f) [●] Termination Fee 26.3 [●] Maximum Liability 24.1(a)(vi) [●] Cost or Savings Threshold 1.1 [●] Governing Law5 37.14 [●] Mediation Rules 38.2 [●] Expert Appointing Authority6 38.3(c) [●] Arbitration Language 38.4(b) [●] Arbitration Seat7 38.4(c) [●] Lender Direct Agreement 4.4(a) [Applicable] [Not Applicable]. Man-Made Underground Structures as a Relevant Event entitling time relief8 6.3 and 13.3(b) [Applicable] [Not Applicable]. Man-Made Underground Structures entitling cost relief9 6.3 and 13.3(b) [Applicable] [Not Applicable].
KEY INFORMATION TABLE. Lead Applicant
KEY INFORMATION TABLE. Application Name Cost total for eligible activity (A) supplemental action plan activities in support of an existing Action Plan
KEY INFORMATION TABLE. Commercial Information Options Subject Clause Key Information Project Information Subject Clause Key Information
Government 1.1 [●] Insolvency Event paragraph (e) 1.1 [●] Installation Contractor 1.1 [●] Landowner 1.1 [●] Network Operator 1.1 [●] Nominated Account 1.1 [●] Project Agreements 1.1 [Implementation Agreement Supply Agreement, O&M Agreement, Grid Connection Agreement, Land Agreement, Finance Agreements, any meter operating agreement and any electricity supply agreement]. Relevant Jurisdiction 1.1 [●] Site 1.1 [●] Buyer Notice Details 20.1 For the attention of: [●] Address: [●] Tel. No: [●] Fax No. [●] Email: [●] Project Company Notice Details 20.1 For the attention of: [●] Address: [●] Tel. No: [●] Fax No. [●] Email: [●]
KEY INFORMATION TABLE. Subject Clause Key Information
(a) [ICC arbitration in [insert seat of arbitration]8 [non-exclusive jurisdiction of the courts of [insert jurisdiction]9]10. DSRA Funding Period 27 [insert period of months e.g. 6 or 12 months]. Final Maturity Date 15 [insert agreed date].
(d) [means any indebtedness for or in respect of: moneys borrowed; any amount raised by acceptance under any acceptance credit facility or dematerialised equivalent; any amount raised pursuant to any note purchase facility or the issue of bonds, notes, debentures, loan stock or any similar instrument; the amount of any liability in respect of any lease or hire purchase contract which would in accordance with [IFRS]11, be treated as a finance or capital lease; receivables sold or discounted (other than any receivables to the extent they are sold on a non-recourse basis); any amount raised under any other transaction (including any forward sale or purchase agreement) of a type not referred to in any other paragraph of this definition having the commercial effect of a borrowing; any derivative transaction entered into in connection with protection against or benefit from fluctuation in any rate or price (and when calculating the value of any derivative transaction, only the marked to market value (or if any actual amount is due as a result of the termination or close-out of that derivative transaction, that amount) shall be taken into account); any counter-indemnity obligation in respect of a guarantee, indemnity, bond, standby or documentary letter of credit or any other instrument issued by a bank or financial institution; and the amount of any liability in respect of any guarantee or indemnity for any of the items referred to in paragraphs (a) to (h) above.] Governing Law of the Finance Agreements 43 [insert governing law]. Hedging Strategy 46 [Applicable] [Not Applicable]. [IFRS 3712 Means the International Financial Reporting Standards (formerly International Accounting Standards), which are the standards issued by the International Accounting Standards Board together with the interpretations issued by the International Financial Reporting Interpretations Committee of the International Accounting Standards Board (as amended, supplemented or re-issued from time to time) applied on a consistent basis both as to classification of items and amounts.] Information Covenants – threshold amounts for reporting details of any damage or destruction to the Project assets or of any insurance claim 35...