Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever. (ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties. (iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority. (iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i). (v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party. (vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway. (vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.
MANAGEMENT OF THE BUSINESS Pursuant to Section ▇▇-▇▇-▇▇▇ of the Act, and as stated in its Articles, the Company’s day to day affairs are managed by the Member. The Member is responsible for the daily operations of the business.
Management of the Company The Company's business and affairs shall be conducted and managed by the Member(s) in accordance with this Agreement and the laws of the State of the Formation. Single-Member (Applies ONLY if Single-Member): The Member(s) of the Company has sole authority and power to act for or on behalf of the Company, to do any act that would be binding on the Company or incur any expenditures on behalf of the Company. The Member(s) shall not be liable for the debts, obligations, or liabilities of the Company, including under a judgment, decree, or order of a court. The Company is organized as a “member-managed” limited liability company. The Member(s) is designated as the initial managing Member(s). Multi-Member (Applies ONLY if Multi-Member): Except as expressly provided elsewhere in this Agreement, all decisions respecting the management, operation, and control of the business and affairs of the Company and all determinations made in accordance with this Agreement shall be made by the affirmative vote or consent of Member(s) holding a majority of the Members’ Percentage Interests. Notwithstanding any other provision of this Agreement, the Member shall not, without the prior written consent of the unanimous vote or consent of the Member(s), sell, exchange, lease, assign or otherwise transfer all or substantially all of the assets of the Company; sell, exchange, lease (other than space leases in the ordinary course of business), assign or transfer the Company’s assets; mortgage, pledge or encumber the Company’s assets other than is expressly authorized by this Agreement; prepay, refinance, modify, extend or consolidate any existing mortgages or encumbrances; borrow money on behalf of the Company; lend any Company funds or other assets to any person or entity; establish any reserves for working capital repairs, replacements, improvements or any other purpose; confess a judgment against the Company; settle, compromise or release, discharge or pay any claim, demand or debt, including claims for insurance; approve a merger or consolidation of the Company with or into any other limited liability company, corporation, partnership or other entity; or change the nature or character of the business of the Company. The Member(s) shall receive such sums for compensation as Member(s) of the Company as may be determined from time to time by the affirmative vote or consent of Member(s) holding a majority of the Member(s)’ Percentage Interests.
Management of Change 29.2.1 The parties to this collective agreement accept that change in the health service is necessary in order to ensure the efficient and effective delivery of health services. They recognise a mutual interest in ensuring that health services are provided efficiently and effectively, and that each has a contribution to make in this regard. 29.2.2 Regular consultation between the employer, its employees and the union is essential on matters of mutual concern and interest. Effective communication between the parties will allow for: (a) improved decision making; (b) greater cooperation between employer and employees; and (c) a more harmonious, effective, efficient, safe and productive workplace.
Patch Management All workstations, laptops and other systems that process and/or store County PHI or PI must have critical security patches applied, with system reboot if necessary. There must be a documented patch management process which determines installation timeframe based on risk assessment and vendor recommendations. At a maximum, all applicable patches must be installed within 30 days of vendor release.