Observations and Inspections Clause Samples

Observations and Inspections. The Contractor shall provide Owner and Architect access to the Work, wherever located and in whatever stage of construction for the purpose of providing inspections and observations necessary to assess compliance with applicable codes and to identify the quality and quantity of Work performed. If a portion of the Work is covered contrary to the Architect's request or to the requirements expressed in the Contract Documents, it must be uncovered to allow the requested inspection or observation and replaced at the Contractor's expense without change in Contract Time. If a portion of the Work has been covered for which the Owner or Architect has not specifically requested prior observation, the Architect may request to see such Work and it shall be uncovered by the Contractor. If such Work has been completed in accordance with the Contract Documents, the cost for uncovering and replacement shall be born by the Owner and implemented through a Change Order recommended by the Architect and approved by the Owner. If such Work was inspected and found not to be in conformance with the Contact Documents, the Contractor shall pay the cost of uncovering and replacement without a change in Contract Time.
View SourceView Similar (15)
Observations and Inspections. Government personnel other than Contracting Officer Representatives (CORs) may occasionally observe contract operations. These personnel may not, however, interfere or provide direction to the contractor performance.
View SourceView Similar (6)
Observations and Inspections. The CONTRACTOR shall provide CITY and Project Engineer access to the Work, wherever located and in whatever stage of construction for the purpose of providing inspections and observations necessary to assess compliance with applicable codes and to identify the quality and quantity of Work performed. If a portion of the Work is covered contrary to the Project Engineer’s request or to the requirements expressed in the Contract Documents, it must be uncovered to allow the requested inspection or observation and replaced at the CONTRACTOR’s expense without change in Contract Time. If a portion of the Work has been covered for which the CITY or Project Engineer as not specifically requested prior to observation, the Project Engineer may request to see such Work and the CONTRACTOR shall uncover it. If such Work has been completed in accordance with the Contract Documents, the cost for uncovering and replacement shall be born by the CITY and implemented through a Change Order recommended by the Project Engineer and approved by the CITY. If such Work was inspected and found not to be in conformance with the Contract Documents, the CONTRACTOR shall pay the cost of uncovering and replacement without a change in Contract Time.
View Source
Observations and Inspections. The CONTRACTOR shall provide OWNER and OWNER’S REPRESENTATIVE access to the Work, wherever located and in whatever stage of construction for the purpose of providing inspections and observations necessary to assess compliance with applicable codes and to identify the quality and quantity of Work performed. If a portion of the Work is covered contrary to the OWNER’S REPRESENTATIVE's request or to the requirements expressed in the Contract Documents, it must be uncovered to allow the requested inspection or observation and replaced at the CONTRACTOR's expense without change in Contract Time. If a portion of the Work has been covered for which the OWNER or OWNER’S REPRESENTATIVE has not specifically requested prior observation, the OWNER’S REPRESENTATIVE may request to see such Work and it shall be uncovered by the CONTRACTOR. If such Work has been completed in accordance with the Contract Documents, the cost for uncovering and replacement shall be born by the OWNER and implemented through a Change Order recommended by the OWNER’S REPRESENTATIVE and approved by the OWNER. If such Work was inspected and found not to be in conformance with the Contact Documents, the CONTRACTOR shall pay the cost of uncovering and replacement without a change in Contract Time.
View Source
Observations and Inspections. Each Party shall have the right at its own expense to observe and inspect the Facilities of the other Party, including the operations and records, for the purpose of verifying that the other Party is conducting its operations and record keeping in accordance with this Agreement. Any such observation or inspection shall be upon reasonable notice and during normal business hours. Seller shall have the right to observe and inspect the Purchaser’s Facilities and records related to this Agreement, and Purchaser shall have the right to observe and inspect the Seller’s Facilities and records related to this Agreement.
View Source

Related to Observations and Inspections

  • Tests and Inspections § 15.5.1 Tests, inspections and approvals of portions of the Work shall be made as required by the Design-Build Documents and by applicable laws, statutes, ordinances, codes, rules and regulations or lawful orders of public authorities. Unless otherwise provided, the Design-Builder shall make arrangements for such tests, inspections and approvals with an independent testing laboratory or entity acceptable to the Owner, or with the appropriate public authority, and shall bear all related costs of tests, inspections and approvals. The Design-Builder shall give the Owner timely notice of when and where tests and inspections are to be made so that the Owner may be present for such procedures. The Owner shall bear costs of (1) tests, inspections or approvals that do not become requirements until after bids are received or negotiations concluded, and (2) tests, inspections or approvals where building codes or applicable laws or regulations prohibit the Owner from delegating their cost to the Design-Builder. § 15.5.2 If the Owner determines that portions of the Work require additional testing, inspection or approval not included under Section 15.5.1, the Owner will instruct the Design-Builder to make arrangements for such additional testing, inspection or approval by an entity acceptable to the Owner, and the Design-Builder shall give timely notice to the Owner of when and where tests and inspections are to be made so that the Owner may be present for such procedures. Such costs, except as provided in Section 15.5.3, shall be at the Owner’s expense. § 15.5.3 If such procedures for testing, inspection or approval under Sections 15.5.1 and 15.5.2 reveal failure of the portions of the Work to comply with requirements established by the Design-Build Documents, all costs made necessary by such failure shall be at the Design-Builder’s expense. § 15.5.4 Required certificates of testing, inspection or approval shall, unless otherwise required by the Design-Build Documents, be secured by the Design-Builder and promptly delivered to the Owner. § 15.5.5 If the Owner is to observe tests, inspections or approvals required by the Design-Build Documents, the Owner will do so promptly and, where practicable, at the normal place of testing. § 15.5.6 Tests or inspections conducted pursuant to the Design-Build Documents shall be made promptly to avoid unreasonable delay in the Work.

  • Audits and Inspections At any time during normal business hours and as often as the City may deem necessary, Service Provider shall make available to the City for the City’s examination all of Service Provider’s records and documents with respect to all matters covered by this Agreement and, furthermore, Service Provider will permit the City to audit, examine and make copies, excerpts or transcripts from such records, and to make audits of all contracts, invoices, materials, payrolls, records of personnel, conditions of employment and other data relating to all matters covered by this Agreement.

  • TESTING AND INSPECTION 29 6.1 Pre-Commercial Operation Date Testing and Modifications. 29