Reduction or Elimination of Work Clause Samples

The "Reduction or Elimination of Work" clause allows one party, typically the client or project owner, to decrease the scope of work or remove certain tasks from a contract after it has been executed. In practice, this clause outlines the procedures for notifying the contractor of changes, how adjustments to compensation or timelines will be handled, and any rights the contractor may have to claim costs already incurred. Its core function is to provide flexibility for the client to adapt the project to changing needs or circumstances while establishing a fair process for managing the impact on the contractor.
Reduction or Elimination of Work. Any individual who has a continuing appointment may be laid off if the ▇▇▇▇ determines that the work performed by the individual is being eliminated, reduced, or reassigned to a tenure-stream faculty member. In such cases, the individual shall be entitled to notice at least one year prior to the effective date of the layoff. Written reasons for the layoff shall be provided to the individual and to the Union. Such a layoff shall not be deemed retrenchment under Article 22, and none of the terms of that article shall apply. The work being done by the individual identified for layoff may continue, provided the remaining work is (1) less than 50 percent FTE and, (2) performed at a reduced level by remaining non-tenure-track faculty members, if those remaining faculty members are qualified to perform that work and have greater seniority, or if the remaining faculty member has additional duties that are outside the qualifications of the terminated non-tenure-track faculty member.
View SourceView Similar (14)
Reduction or Elimination of Work. Any individual who has a continuing appointment may be laid off if the ▇▇▇▇ determines that the work performed by the individual is being eliminated, reduced, or reassigned to a tenure-stream faculty member. In such cases, the individual shall be entitled to notice at least one year prior to the effective date of the layoff. Written reasons for the layoff shall be provided to the individual and to the Union. Such a layoff shall not be deemed retrenchment under Article 22, and none of the terms of that article shall apply. The work being done by the individual identified for layoff may continue, provided the remaining work is less than 50 percent FTE, and be performed at a reduced level by remaining non-tenure-track faculty members if those
View SourceView Similar (3)

Related to Reduction or Elimination of Work

  • Suspension of Work and Termination 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 60 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension.

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. 13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition. 13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and 13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph 13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State. 13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal. 13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.

  • Location of Work The Executive shall be based in the United States in West Orange, New Jersey. However, the Executive agrees to undertake whatever domestic and worldwide travel is required by the Company. The Executive shall not be required or permitted to relocate without the mutual, written consent of the Executive and the Company.

  • Continuation of Work Pending the resolution of any dispute or claim pursuant to this Article 11, the Parties agree that performance of all obligations will be pursued diligently.