Labor Harmony The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows: (a) In any contract or undertaking which Tenant may make with a contractor for work in the Premises, provision shall be made for the dismissal from the job of workmen whose work is unskilled or otherwise objectionable, in the Director’s (and, for this purpose, “the Director” shall include a reference to the Airport’s Architect) reasonable judgment. Tenant shall cause any such workmen to be discharged from the project within twenty-four (24) hours after Director shall give notice to Tenant requiring such discharge. (b) Tenant shall use, and Tenant shall require its contractor and subcontractors to use, their respective best efforts to prevent work stoppages on the Premises, and/or elsewhere on the Airport, to the extent attributable to work being performed on the Premises, irrespective of the reason of any such stoppage. In the event that the conduct or presence of any employee(s) of Tenant or Tenant’s contractor(s) or subcontractor(s) causes a labor dispute or work stoppage, Tenant shall have such employee(s) immediately removed from the Airport upon Director’s request. (c) Tenant shall include, and shall cause its contractor to include, the following clause in all contracts with its general contractors and subcontractors: There shall be no manifestations on the project of any dispute between any labor organization and any Tenant contractor or subcontractor, including but not limited to, any area standards picketing against said contractor or subcontractor. Should there be any manifestation of a labor dispute between any Tenant contractor or subcontractor and any union, which results in a stoppage of work on the part of said contractor or subcontractor’s employees or the employees of any other employer or supplier on the project or at the Airport, which in the sole judgment of the Director will cause, or is likely to cause, unreasonable delay in the progress of construction or operation of any business at the Airport, then upon written notice from Director, Tenant shall declare the contractor or subcontractor in default of its contract, and upon such notice, Tenant shall have the right to take such steps as are necessary to finish the uncompleted portion of the work to be performed by the contractor or subcontractor. (d) Without limiting the generality of indemnities elsewhere in this Lease, Tenant shall indemnify, defend, and hold harmless City and each City Entity for any and all Losses which arise from the actions taken pursuant to this Section 7.9.
Compliance with Health Care Laws Each of the Company and its Subsidiaries is, and at all times has been, in compliance in all material respects with all applicable Health Care Laws, and has not engaged in activities which are, as applicable, cause for false claims liability, civil penalties, or mandatory or permissive exclusion from Medicare, Medicaid, or any other state or federal health care program. For purposes of this Agreement, “Health Care Laws” means: (i) the Federal Food, Drug, and Cosmetic Act (21 U.S.C. §§ 301 et seq.), the Public Health Service Act (42 U.S.C. §§ 201 et seq.), and the regulations promulgated thereunder; (ii) all applicable federal, state, local and all applicable foreign health care related fraud and abuse laws, including, without limitation, the U.S. Anti-Kickback Statute (42 U.S.C. Section 1320a-7b(b)), the U.S. Physician Payment Sunshine Act (42 U.S.C. § 1320a-7h), the U.S. Civil False Claims Act (31 U.S.C. Section 3729 et seq.), the criminal False Claims Law (42 U.S.C. § 1320a-7b(a)), all criminal laws relating to health care fraud and abuse, including but not limited to 18 U.S.C. Sections 286 and 287, and the health care fraud criminal provisions under the U.S. Health Insurance Portability and Accountability Act of 1996 (“HIPAA”) (42 U.S.C. Section 1320d et seq.), the exclusion laws (42 U.S.C. § 1320a-7), the civil monetary penalties law (42 U.S.C. § 1320a-7a), HIPAA, as amended by the Health Information Technology for Economic and Clinical Health Act (42 U.S.C. Section 17921 et seq.), and the regulations promulgated pursuant to such statutes; (iii) Medicare (Title XVIII of the Social Security Act); (iv) Medicaid (Title XIX of the Social Security Act); (v) the Controlled Substances Act (21 U.S.C. §§ 801 et seq.) and the regulations promulgated thereunder; and (vi) any and all other applicable health care laws and regulations. Neither the Company nor, to the knowledge of the Company, any subsidiary has received notice of any claim, action, suit, proceeding, hearing, enforcement, investigation, arbitration or other action from any court or arbitrator or governmental or regulatory authority or third party alleging that any product operation or activity is in material violation of any Health Care Laws, and, to the Company’s knowledge, no such claim, action, suit, proceeding, hearing, enforcement, investigation, arbitration or other action is threatened. Neither the Company nor, to the knowledge of the Company, any subsidiary is a party to or has any ongoing reporting obligations pursuant to any corporate integrity agreements, deferred prosecution agreements, monitoring agreements, consent decrees, settlement orders, plans of correction or similar agreements with or imposed by any governmental or regulatory authority. Additionally, neither the Company, its Subsidiaries nor any of its respective employees, officers or directors has been excluded, suspended or debarred from participation in any U.S. federal health care program or human clinical research or, to the knowledge of the Company, is subject to a governmental inquiry, investigation, proceeding, or other similar action that could reasonably be expected to result in debarment, suspension, or exclusion.
Contractor Standards Contractor shall comply with Contractor Standards provisions codified in the SDMC. Contractor understands and agrees that violation of Contractor Standards may be considered a material breach of the Contract and may result in Contract termination, debarment, and other sanctions.
Fair Employment Practices and Americans with Disabilities Act Party agrees to comply with the requirement of Title 21V.S.A. Chapter 5, Subchapter 6, relating to fair employment practices, to the full extent applicable. Party shall also ensure, to the full extent required by the Americans with Disabilities Act of 1990, as amended, that qualified individuals with disabilities receive equitable access to the services, programs, and activities provided by the Party under this Agreement. Party further agrees to include this provision in all subcontracts.