Delays Due to Force Majeure Sample Clauses

POPULAR SAMPLE Copied 3 times
Delays Due to Force Majeure. Subject to Section 3.02(f) and Seller’s compliance with its obligations as the Claiming Party under Section 23.02, if Seller has not satisfied the conditions set forth in Section 2.04 for the Initial Delivery Date of the Project by the Expected Initial Delivery Date due to Force Majeure, then the Expected Initial Delivery Date will be extended on a day-for-day basis for the duration of the Force Majeure.
View SourceView Similar (4)
Delays Due to Force Majeure. If, due to Force Majeure, the implementation of manufacturing, delivery, construction, installation, training, ACCEPTANCE TEST or any other program shall be temporarily prevented, then the period of program implementation so prevented shall be revised by extending the implementation period of the affected activity/program. If this shall affect the completion period as mentioned in this AGREEMENT, then Parties shall agree to extend the completion period of the WORKS with the number of days at least equal to the prevention of the program implementation mentioned above plus a reasonable time necessary to re-mobilise and to cover the impact of the Force Majeure (e.g. bad weather).
View SourceView Similar (2)
Delays Due to Force Majeure. In the event Contractor or Owner is delayed in performing any of their respective obligations pursuant to the Contract Documents and such delay is caused by acts of God, war, riots, civil insurrection, acts of the public enemy, accidents, acts of civil or military authority, fires, floods, or earthquakes, beyond the reasonable control of the party delayed, such delay shall be excused and the period of such delay shall be added to the time for performance of the obligation delayed, unless the date, schedule or time period for performance of the obligation is expressly stated in the Contract Documents to be guaranteed. Contractor acknowledges, however, that it is familiar with the general weather conditions, and seasonal changes thereof, at the Site and that no delays shall be excused on account of the occurrence of such seasonal weather, and Contractor has budgeted for such contingencies in the timing of its Schedule pursuant to Article VIII, TIMING AND COMPLETION OF WORK, hereof. The Contractor further acknowledges and agrees that such extension in the time for performance shall only be permitted if the delay: (i) is not caused, or could not have been anticipated by the Contractor; and (ii) is of a duration not less than one (1) day of the Work. Contractor shall only be entitled to an extension of the time if the performance of the Work is not, was not, or would not have been delayed by any other cause for which the Contractor is not entitled to an extension in the time for performance.
View SourceView Similar (5)
Delays Due to Force Majeure. Subject to Section 11.1(b)(iii) and Seller’s compliance with its obligations as the Claiming Party under Article 20, if Seller has not satisfied the conditions set forth in Section 3.1 for the Initial Delivery Date of the DR Resource by the Expected Initial Delivery Date due to Force Majeure, then the Expected Initial Delivery Date will be extended on a day-for-day basis for the duration of the Force Majeure. No Liability of SCE. SCE shall have no liability to Seller, regardless of cause (including any act or omission of SCE, including as buyer under this Agreement or as the owner of the distribution electrical system) for (a) any delay or failure by Seller to achieve the Initial Delivery Date by the Expected Initial Delivery Date, and (b) any costs or damages incurred by Seller as a result thereof or any reduction in Seller’s Delivered Capacity Payments and Delivered Energy Payments resulting from any delay in achieving the Initial Delivery Date by the Expected Initial Delivery Date. DESIGN AND CONSTRUCTION OF STORAGE UNITS Seller’s Obligations. At no cost to SCE, Seller shall: Design and construct, or refurbish the Project as required for Seller to perform its obligations under this Agreement; Within [number] [#] days prior to the Expected Initial Delivery Date, Seller shall file all applications or other appropriate requests to acquire and maintain all permits, licenses, certifications and approvals necessary for the construction or refurbishment, operation and maintenance of the Project (the “Required Permits”), including permits to construct from the applicable Air Pollution Control District, or a Facility and Site Certification from the CEC (pursuant to California Public Resources Code Sections 25500-25543), as applicable, and obtain all Required Permits on or before [Date] (the “Required Permit Date”); As applicable, complete all environmental impact assessments or studies conducted by or for Governmental Bodies pursuant to regulatory programs approved and certified under the California Environmental Quality Act, or environmental impact statements or studies conducted pursuant to the National Environmental Policy Act including obtaining public review and certification of any final documents relating to any environmental impact assessment or studies; As required to achieve Commercial Operation for each Storage Unit, furnish and install all Protective Apparatus as SCE reasonably determines to be necessary for proper and safe operation of the Project w...
View SourceView Similar (2)
Delays Due to Force Majeure. In the event Contractor or Owner is delayed in performing any of their respective obligations in the Contract and such delay is caused by acts of God, war, riots, civil insurrection, acts of the public enemy, accidents, acts of civil or military authority, fires, floods, or earthquakes, beyond the reasonable control of the party delayed, such delay shall be excused and the period of such delay shall be added to the time for performance of the obligation delayed, unless the date, schedule or time period for performance of the obligation is expressly stated in the Contract to be guaranteed. Contractor acknowledges, however, that it is familiar with the general weather conditions, and seasonal changes thereof, at the Site and that no delays shall be excused on account of the occurrence of such seasonal weather, and Contractor has budgeted for such contingencies in the timing of its Schedule pursuant to Article VIII, TIMING AND COMPLETION OF WORK, hereof.
View SourceView Similar (2)
Delays Due to Force Majeure. If at any time during the continuance of the contract the performance in whole or part by either party of any obligation under the contract shall be prevented or delayed by reasons of war, hostility acts of public enemy, civil commotion, sabotage. Fires, floods, explosions, epidemics, quarantine restrictions, strikes, lockouts or acts of God (hereinafter referred to as events) then provided notice of the happenings of any such events if given by either party or the other within twenty one days from the date of occurrence thereof, neither party shall by reasons of such event, be entitled to terminate the contract nor shall either party have any claim for damage against whether in respect of such non-performance or delay in performance. Deliveries or acceptance of deliveries under the contract shall be resumed as soon as practicable after such event has come to an end or ceased to exist and the decision of the OMPL as to whether the deliveries or acceptance of deliveries have to be so resumed or not shall be final and conclusive provided further if the performance in whole or part or any obligation under the contract is prevented or delayed by reasons of any such event for period exceeding 90 days either party may at its option terminate the contract.
View Source
Delays Due to Force Majeure. If delay in delivery is caused by a Force Majeure Event (as defined in the Unibap General Terms and Conditions) the time for delivery shall be extended by a period which is reasonable with regard to the circumstances in the case. The time for delivery shall be extended even if the reason for delay occurs after the originally agreed time for delivery.
View Source
Delays Due to Force Majeure. Rader shall be granted an extension of time, without incu▇▇▇▇▇ delay penalties or damages, to deliver the Railcars should the delay be the result of Force Majeure as defined in Section 10 hereof. 15 FINANCIAL STATEMENT BY FTI Commencing with financials for the calendar month ending November 30, 1996. FTI shall provide Rader with a monthly financial statement until the final paymen▇ ▇▇ made pursuant to Paragraph 7.2 (i) above.
View Source
Delays Due to Force Majeure. Subject to Section 3.02(f) and Seller’s compliance with its obligations as the Claiming Party under Section 23.02, if Seller has not satisfied the conditions set forth in Section 2.04 for the Initial Delivery Date of the Project by the Expected Initial Delivery Date due to Force Majeure, then the Expected Initial Delivery Date will be extended on a day-for-day basis for the duration of the Force Majeure. No Liability of SCE. SCE shall have no liability to Seller, regardless of cause (including any act or omission of SCE, including as Buyer under this Agreement, retail provider of electric energy, or as a PTO) for (a) any delay or failure by Seller to achieve the Initial Delivery Date by the Expected Initial Delivery Date, (b) any costs or damages incurred by Seller as a result thereof or any reduction in Seller’s Monthly Capacity Payments resulting from any delay in achieving the Initial Delivery Date by the Expected Initial Delivery Date, or (c) a reduction in the Term or the Delivery Period. Seller’s Queue Position. Seller must not withdraw the Interconnection Queue Position identified in Section 1.03(c) or assign or transfer that Interconnection Queue Position to any entity or for the benefit of any other agreement other than this Agreement without SCE’s prior written consent. EVENTS OF DEFAULT; REMEDIES; TERMINATION
View Source

Related to Delays Due to Force Majeure

  • Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.

  • Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following: i) acts of God; ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities; iii) acts of war (whether declared or undeclared), invasion or civil unrest; iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement); v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals; vi) earthquakes, explosions, accidents, landslides; fire; vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality; viii) chemical or radioactive contamination or ionizing radiation; or ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs; x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.

  • Force Majeure Event 16.1 If a Force Majeure Event gives rise to a failure or delay in either party performing any obligation under this Agreement (other than any obligation to make a payment), that obligation will be suspended for the duration of the Force Majeure Event. 16.2 A party that becomes aware of a Force Majeure Event which gives rise to, or which is likely to give rise to, any failure or delay in that party performing any obligation under this Agreement, must: (a) promptly notify the other; and (b) inform the other of the period for which it is estimated that such failure or delay will continue. 16.3 A party whose performance of its obligations under this Agreement is affected by a Force Majeure Event must take reasonable steps to mitigate the effects of the Force Majeure Event.