Modifications of Specifications Clause Samples

Modifications of Specifications. The Specifications may be modified and/or changed by written agreement of the parties hereto, provided that such modifications and/or changes or an accumulation thereof will not, in the SELLERS’ judgment, adversely affect the BUILDER’s planning or program in relation to the BUILDER’s other commitments, and provided, further, that the BUYER shall first agree, before such modifications and/or changes are carried out, to alterations in the Contract Price, the Delivery Date and other terms and conditions of this Contract and the Specifications occasioned by or resulting from such modifications and/or changes. Such agreement may be effected by exchange of letters signed by the authorized representatives of the parties hereto or by facsimile or e-mail confirmed by such letters manifesting agreements of the parties hereto which shall constitute amendments to this Contract and/or the Specifications.

Modifications of Specifications. The Specifications may be modified and/or changed by written agreement of the parties hereto, provided that such modifications and/or changes or an accumulation thereof will not, in the BUILDER’s judgement, adversely affect the BUILDER’s planning or program in relation to the BUILDER’s other commitments, and provided, further, that the BUYER shall first agree, before such modifications and/or changes are carried out, to alterations in the Contract Price, the Delivery Date and other terms and conditions of this Contract and the Specifications occasioned by or resulting from such modifications and/or changes. Such agreement may be effected by exchange of letters signed by the authorized representatives of the parties hereto or by facsimile confirmed by such letters manifesting agreements of the parties hereto which shall constitute amendments to this Contract and/or the Specifications. The BUILDER may make minor changes to the Specifications without alterations to the Contract Price, if found necessary for introduction of improved production methods.

Modifications of Specifications. 1. The Buyer may, from time to time, by a written Change Order Form (or such other Form upon which the Parties mutually agree) issued to the Builder, make changes in Specifications or drawings, issue additional instructions, require additional work or direct the omission of work previously ordered. The provisions of this Agreement shall apply to all such changes, modifications and additions with the same force and effect as if they were embodied in the original Specifications and drawings. 2. Except as provided for in subparagraph 3 below, changes to the Specifications proposed by the Builder shall be detailed on a Change Order Form by the Builder’s authorized representative for Buyer approval. The provisions of this Agreement shall apply to all such changes, modifications and additions with the same force and effect as if they were embodied in the original Specifications and drawings. 3. The Builder shall make no changes or variations from the Drawings or Specifications except on written order of the Buyer’s Representative through the vehicle of a Change Order Form or through a design change reflected in a Buyer-approved plan or drawing, it being understood that the Specifications and Drawings are for guidance in developing the final design and production drawings by Builder. Buyer and Builder agree that, as the detailed design progresses, some changes from the Specifications and the Drawings may be required to meet performance requirements or may be useful to the Builder to improve cost effectiveness of the project without any reductions in or to fundamental performance criteria, serviceability, operability or maintenance costs to the Buyer. Such changes, made in the development of the final design or production drawings, will only be subject to approval by the Buyer and will not be subject to Change Order which requires any adjustment to Contract Price. [**] Confidential Treatment 19 4. Changes or variations to existing work, as well as new items, are to be fully described and priced on the Change Order Form. Each Change Order will be priced by the Builder and signed by the Buyer’s Representative prior to the start of any “change” work. No claims for an addition to the contract amount shall be valid unless this procedure is done. 5. For any Change Order, including Change Orders requesting changes to the delivery date based upon late delivery of the Vessel or Owner furnished equipment, delays in Owner-furnished work, or Force Majeure, the Builder must no...

Modifications of Specifications. The SPECIFICATIONS may be modified and/or changed by prior written agreement of the parties hereto, provided that such modifications and/or changes or an accumulation thereof will not, in the SELLER’S and/or the BUILDER’s judgment, acting reasonably, adversely affect the BUILDER’s planning or program in relation to the BUILDER’s other commitments, and provided, further, that the BUYER shall first agree, before such modifications and/or changes are carried out, to alterations in the CONTRACT PRICE, the DELIVERY DATE as defined in Article VII hereof and other terms and conditions of this CONTRACT and the SPECIFICATIONS occasioned by or resulting from such modifications and/or changes. Such agreement may be effected by exchange of letters signed by the authorized representatives of the parties hereto or by facsimile confirmed by such letters manifesting agreements of the parties hereto which shall constitute amendments to this CONTRACT and/or the SPECIFICATIONS. The SELLER may cause the BUILDER to make minor changes to the SPECIFICATIONS, if found necessary for introduction of improved production methods or otherwise, provided that the SELLER and/or the BUILDER shall first obtain the BUYER’s approval which shall not be unreasonably withheld.

Modifications of Specifications. The Specifications may be modified and/or changed by written agreement of the parties hereto, provided that such modifications and/or changes or an accumulation thereof will not, in the Builder’s judgement, adversely affect the Builder’s planning or program, and provided, further, that the Owner shall first agree, before such modifications and/or changes are carried out, to alterations in the Contract Price, the Delivery Date and other terms and conditions of this Contract and Specifications occasioned by or resulting from such modifications and/or changes. Such agreement may be effected by exchange of letters signed by the authorised representatives of the parties hereto or by faxes confirmed by such letters manifesting agreements of the parties hereto which shall constitute amendments to this Contract and/or the Specifications. The Builder may make minor changes to the Specifications, if found necessary for introduction of improved production methods or otherwise as long as they are of better or of equal quality, provided that the Builder shall first obtain the Owner’s approval which shall not be unreasonably withheld

Modifications of Specifications. The BUYER understands and pays the respect for the BUILDER’s policy and intention about the design of the VESSEL which is one of the series of the BUILDER’s standard vessels as provided in ARTICLE I.

Modifications of Specifications. 1. The Specifications may be modified and/or changed by written agreement of the parties, provided that such modifications and/or changes or an accumulation thereof will not, in Builder’s reasonable judgment, adversely affect Builder’s planning or program in relation to Builder’s other commitments, and provided, further, that Buyer shall first agree, before such modifications and/or changes are carried out, to alterations in the Contract Price, the Delivery Date and other terms and conditions of this Contract and Specifications occasioned by or resulting from such modifications and/or changes. Builder agrees to use best commercial efforts to accommodate any such reasonable requests by the Buyer so that any changes and modifications will be made at a reasonable cost and within the shortest period of time as is reasonably possible. 2. Such agreement may be effected by an exchange of letters signed by the authorized representatives of the parties hereto manifesting agreements of the parties hereto, which shall constitute amendments to this Contract and/or the Specifications. 3. Builder may make minor changes to the Specifications, if found necessary for introduction of improved production methods or otherwise, provided that Builder shall first obtain Buyer’s written approval, which shall not be unreasonably withheld, and, if required, the written approval of the Classification Society.