SUBLET WORK Clause Samples

The SUBLET WORK clause defines the conditions under which a contractor may assign or subcontract portions of their contractual obligations to third parties. Typically, this clause requires the contractor to obtain prior written consent from the client or project owner before engaging any subcontractors, and may set standards for the qualifications or performance of those subcontractors. Its core function is to ensure that the quality and accountability of the work are maintained, while giving the client oversight and control over who is performing critical aspects of the project.
POPULAR SAMPLE Copied 1 times
SUBLET WORK. A. If prior to entering into a contract, the contractor has definite knowledge that he/she is taking over a contract for a job that has been partially completed by another contractor, he/she shall notify the LMCC or the Painters and Allied Trades District Council No. 36, in writing, by telephone, by FAX, or by telegram in the area before starting work. Upon receipt of such notice the LMCC or the District Council shall immediately inspect the job and shall advise all journeymen and trust funds, with unpaid claims, of their legal and other enforcement rights. B. Two or more Employers: The Employers party to this Agreement hereby agree that no two or more employers having separate Shop Cards will be allowed to work for each other. Painting Contractors will be permitted to sub-let contracts and in such cases shall mail to the LMCC, prior to the start of such sublet contract work, the list of subcontractors’ names and addresses. The employer agrees that he/she will not sublet or contract to his/her employees. C. Any Employer found guilty of sub-contracting work covered by this Agreement to an unsigned contractor and/or employee shall be assessed liquidated damages in the sum of not less than one thousand dollars ($1,000.00), none of which may be suspended, and the amount of trust fund contributions lost by virtue of the illegal sub-contract, by the LMCC. The assessed damages shall be paid to the Joint Apprenticeship Committee.
View SourceView Similar (5)
SUBLET WORK. A. The parties acknowledge that a close relationship exists between the Employer and its subcontractors on its job sites; and that employment of craftsmen at a particular job site is sporadic, necessitating a ready supply of craftsmen such as are available through the resources of the Union; that precise knowledge concerning present and prospective labor costs is essential to the Employer for the purpose of bidding; and that it is necessary and desirous to reduce the friction that results when union and non-union workers are required to work together at the same job site. The parties recognize the strong interest of the Union in insuring a continuity of hiring hall employment opportunities for its members, and continuity of funding as and for the employee benefit trust funds, to the benefit of its members and their dependents. The parties recognize in this regard that such objectives can best be achieved by requiring that all work described in this Agreement be performed by business concerns signatory to this Agreement. B. Two or More Employers: The Employer Signatory to this Agreement hereby agrees that no two or more Employers having separate shop cards will be allowed to work for each other as employees. The Employer shall not contract or subcontract any job site work heretofore described except to a person, firm, partnership, corporation or other entity that is licensed in accordance with State Law and signatory to this Agreement. The Employer agrees that he will not sublet or contract to his employees. It shall be deemed a violation of this Agreement for any employee to act as a labor contractor. C. The Employer agrees that in the event he subcontracts any work covered by this Agreement, the subcontract shall be in writing and a copy submitted to the Painters and Allied Trades District Council No. 36 and to the LMCC Office prior to commencement of the job by the subcontractor. The LMCC Office shall notify the Employer in writing within seventy-two (72) hours the status of the subcontractor. The subcontracting agreement shall contain a provision that the subcontractor shall be responsible for the observance of all terms and conditions of this Agreement including the payment of wages and other monetary obligations. In the event that any subcontractor fails to pay the wages or other monetary obligations provided under this Agreement, the Employer shall become liable for the payments of such sums and such sums except liquidated damages immediately become ...
View SourceView Similar (2)

Related to SUBLET WORK

  • Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.

  • Tenant’s Work Section 5.1 Tenant will not make any changes to the Premises, the Building, the Building systems, or any part thereof (collectively, “Tenant’s Work”), without Landlord’s consent. Tenant’s Work will be performed, at Tenant’s expense, in a professional manner using new materials of first class quality as reasonably determined by Landlord and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2). Section 5.2 Prior to performing any Tenant’s Work which, pursuant to this Article, requires Landlord’s consent, Tenant will, at Tenant’s expense (a) deliver to Landlord, detailed plans and specifications for Tenant’s Work in form reasonably satisfactory to Landlord prepared and certified by a registered architect or licensed engineer, and suitable for filing with the applicable Authority, if filing is required by Law (“Tenant’s Plans”), (b) obtain Landlord’s approval of Tenant’s Plans (which will not be unreasonably withheld or delayed to the extent Landlord’s consent to Tenant’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article), (c) obtain (and deliver to Landlord copies of) all required authorizations of any Authority, (d) deliver to Landlord certificates (in form reasonably acceptable to Landlord) of worker’s compensation insurance (covering all persons to be employed by Tenant, and all contractors and subcontractors performing any Tenant’s Work), commercial general liability insurance (naming Landlord, Landlord’s managing agent, if any, any Superior Landlord and any Mortgagee as additional insureds) and Builder’s all risk insurance (issued on a completed value basis), in form, with companies, for periods and in amounts reasonably required by Landlord, naming Landlord, Landlord’s managing agent, if any, any Superior Landlord and any Mortgagee as additional insureds. Tenant will promptly reimburse Landlord for any reasonable out-of-pocket expenses incurred by Landlord in connection with Landlord’s review of Tenant’s Plans and inspection of Tenant’s Work, including outside experts retained by Landlord for that purpose. Following the completion of Tenant’s Work, Tenant will, at Tenant’s expense, obtain and deliver to Landlord copies of all authorizations of any Authority required upon the completion of Tenant’s Work and “as-built” plans and specifications for Tenant’s Work prepared as reasonably required by Landlord. Section 5.3 If, in connection with Tenant’s Work or any other act or omission of Tenant or Tenant’s employees, agents or contractors, a mechanic’s lien, financing statement or other lien or violation is filed against Landlord, or any part of the Premises, the Building or Tenant’s Work, Tenant will, at Tenant’s expense, have it removed by bonding or otherwise within 30 days after Tenant receives notice of the filing. Section 5.4 Tenant will not employ, or permit the employment of, any contractor, subcontractor or other worker for purposes of conducting physical work in the Premises, whether in connection with Tenant’s Work or otherwise, if such employment will, in Landlord’s reasonable judgment, interfere or cause conflict with other contractors, subcontractors or workers in the Building. Section 5.5 At Tenant’s request, Landlord will join in any applications for any authorizations required from any Authority in connection with Tenant’s Work (to which Landlord has consented, if required pursuant to this Article), and otherwise cooperate with Tenant in connection with Tenant’s Work, but Landlord will not be obligated to incur any expense or obligation in connection with any such applications or cooperation. Section 5.6 Tenant will not place a load on any floor of the Premises exceeding the floor load per square foot which the floor was designed to carry and which is allowed by any Law. Section 5.7 On or before the Expiration Date, Tenant will, at Tenant’s expense, remove from the Premises and the Building (a) Tenant’s trade fixtures, equipment and personal property which are removable without material damage to the Premises or the Building (“Tenant’s Property”), and (b) any Tenant’s Work which is not an ordinary nonstructural office installation and which Landlord designates for removal in a notice given by Landlord to Tenant on or before the date which is 90 days prior to the Fixed Expiration Date (or five days prior to the Earlier Expiration Date, if applicable), and repair any damage to the Premises or the Building caused by the installation or removal of Tenant’s Property or Tenant’s Work. If, at the time Tenant requests Landlord’s consent to Tenant’s Plans, Tenant requests Landlord to designate the portions of Tenant’s Work which must be removed pursuant to this Section, Landlord will make that designation on the date Landlord gives Landlord’s consent to Tenant’s Plans. Except as expressly provided in this Section, Tenant’s Work will not be removed and will, on the Expiration Date, become the property of Landlord. Any Tenant’s Property or Tenant’s Work (which Tenant was required to remove) which is not removed by Tenant by the Expiration Date will be deemed abandoned and may, at Landlord’s option, be retained as Landlord’s property or disposed of by Landlord at Tenant’s expense.

  • Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter: a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications). b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows: (i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and (ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ of ▇▇▇▇▇ ▇▇▇▇ LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises. c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.

  • Lessee's Improvements Since Lessor is the Insuring Party, Lessor shall not be required to insure Lessee-Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease.

  • Subleased Premises Sublandlord does hereby sublease to Subtenant, and Subtenant does hereby sublease and rent from Sublandlord, (i) the Space and (ii) all permanent improvements within the Space constructed by Landlord or by or on behalf of Sublandlord (collectively, the “Subleased Premises”). Subtenant shall have the right to use in common with Sublandlord and others entitled thereto the common areas of the Project pursuant to the Lease. In addition, subject to the terms, covenants and conditions of this Sublease, Subtenant shall have the exclusive right to use during the Sublease Term (defined below), free of charge, the furniture, fixtures and equipment more particularly described on Schedule A annexed hereto and made a part hereof (the “Personal Property”) located in the Space. Subtenant shall have no obligation whatsoever to repair, replace or maintain the Personal Property, unless any damage thereto is caused by the negligence or willful misconduct of Subtenant. Provided that there is no change in the size of the Subleased Premises between the date of this Sublease and the Commencement Date (defined below) (e.g., there has been no change in the size of the Subleased Premises by reason of any damage or destruction to or condemnation of the Subleased Premises), the parties hereby (i) stipulate that the Space shall be deemed to contain approximately 19,997 rentable square feet upon delivery of the Space by Sublandlord to Subtenant (the “Space Measurement”), (ii) agree that neither party shall have any right to dispute the Space Measurement and (iii) waive any claim in connection with the Space Measurement, regardless of whether the Space is found to have contained more or less than 19,997 rentable square feet upon delivery of the Space to Subtenant. Sublandlord represents and warrants for the benefit of Subtenant that the rentable square footage of the Space was not remeasured pursuant to Section 4 of the Second Amendment and that Sublandlord pays Base Rental for the Space under the Lease and Tenant’s Forecast Additional Rental and Tenant’s Additional Rental for the Space under the Lease on the basis of the Space consisting of 19,997 rentable square feet.