SUPERINTENDENCE BY THE CONTRACTOR Sample Clauses

SUPERINTENDENCE BY THE CONTRACTOR. At all times during performance of this Agreement and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent from its organization who is satisfactory to BSA and has authority to act for the Contractor.
View SourceView Similar (23)
SUPERINTENDENCE BY THE CONTRACTOR. A. The Contractor shall have a competent superintendent on the site at all times during the progress of the Work. Contractor's superintendent must be acceptable to the City. The superintendent shall have such assistants with such individual specialized competencies including, but not limited to, CPM scheduling, as may be necessary to fully understand and oversee all aspects of the Work. The superintendent and his assistants all shall be physically fit for their Work and capable of going to all locations where Work is being performed. A communication to the superintendent or his designated assistants by the City is binding upon the Contractor. The Contractor's superintendent shall be responsible for the prevention of accidents at the site. The Commercial Construction Safety Code of the Arizona Industrial Commission shall apply to all Work, and a copy of the Code shall be available at the site. B. The Contractor shall at all times enforce strict discipline and good order among the workers on the Project and shall not employ or continue to employ any unfit person on the Project or any person not skilled in the work assigned to him. The Contractor shall be responsible to the City for all acts and omissions of its employees, Subcontractors, Suppliers, anyone whom the Contractor may allow to perform or inspect or supervise any Work, and their agents and employees together with anyone whom the Contractor may allow to come on the Project site. In addition, if the Contractor receives written notice from the City to dismiss those subcontractors or employees or one who is a hindrance to proper or timely execution of the Work, the Contractor shall dismiss those employees and agrees to replace those dismissed without delay to the Project and at no additional cost to the City. C. The Contractor shall competently and thoroughly direct and superintend all of the Work and shall be solely responsible for all construction safety, means, methods, techniques, sequences and procedures. It shall coordinate and schedule all Work under this contract, the performance of all its employees, Subcontractors, and Suppliers, and the timely procurement of all necessary labor, materials, equipment, supplies, and all else needed to do the Work.
View SourceView Similar (11)
SUPERINTENDENCE BY THE CONTRACTOR. At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly supervise the work and have on the work site a competent superintendent who has the authority to act and sign for the Contractor.
View Source
SUPERINTENDENCE BY THE CONTRACTOR. At all times during performance of the Work and until such time as the Work is completed and accepted by the City, the Contractor shall directly superintend the Work or assign and have present on the site a competent superintendent satisfactory to the Project Manager. Said superintendent shall have the authority to act on behalf of the Contractor, and communications given to the superintendent shall be as binding as if given to the Contractor.
View Source
SUPERINTENDENCE BY THE CONTRACTOR. At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.
View Source
SUPERINTENDENCE BY THE CONTRACTOR. At all times during performance of this Contract, and until the work is completed and accepted, the Contractor shall directly assign a contract manager, single point of contact for all member jurisdictions to contract as the primary point of contact (POC) for the vendor. The Contractor POC who is satisfactory to the COR and has authority, accountability, and responsibility to act for the Contractor.
View Source

Related to SUPERINTENDENCE BY THE CONTRACTOR

  • Superintendent The Contractor shall employ a competent superintendent and necessary assistants who shall be in attendance at the Project site during the progress of the Work. The superintendent shall represent the Contractor and all communications given to the superintendent shall be as binding as if given to the Contractor. All Communications shall be in writing when made or shall be confirmed in writing, by the Contractor, within twenty-four (24) hours of the communication.

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

  • Superintendent of Schools The duly appointed executive officer of the Owner authorized to act by and through The School Board of Broward County, Florida. Referred to hereinafter as the Superintendent.