Excusable Delay Event definition

Excusable Delay Event means a Delay Event directly caused by events beyond the control of both Contractor and the District, including Force Majeure events, which is not concurrent with an Inexcusable Delay Event and which could not have been avoided by Contractor through reasonable mitigation measures.
View Source
Excusable Delay Event means a delay that results from: (1) an event described in Section 18 of this Agreement that impacts Grantee’s ability to achieve Final Completion of the Project- including, but not limited to make-ready work that is not completed within six (6) months of Grantee’s submission of a proper application for utility pole attachments.
View Source
Excusable Delay Event has the meaning set out in Section 12.7(d) of this Schedule 2 [General Conditions];
View Source

Examples of Excusable Delay Event in a sentence

  • The Affected Party shall use its reasonable endeavours to remove the effect of each Excusable Delay Event affecting the performance of its obligations under this Agreement.

  • The TAT will be subject to clock stop for any Excusable Delay Event as defined below.

  • The TAT will be extended by the duration of any resolution of external damage or unexpected findings or any Excusable Delay Event.

  • If there are delays beyond Comcast’s control in obtaining permits, Comcast should notify the County so the County can assist in obtaining said permits; provided, however, that the date for Final Completion will be extended for each day of delay caused by the occurrence of an Excusable Delay Event, or by mutual written agreement by.

  • Therefore, the parties agree that the Milestones shall be extended in the event and to the extent of the number of Days that Work on the Critical Path of the then- current GMP Construction Schedule is delayed by a an Excusable Delay Event.

  • A Party that becomes aware of any matter likely to constitute an Excusable Delay Event affecting its obligations under this Agreement shall immediately give notice of that fact, and of all relevant particulars of which it is aware, to the other Party.

  • The Parties expressly acknowledge that Excusable Delay Events do not include and cannot be caused by labor strikes, lockouts, or other labor disturbances, or the non-performance of subcontracts or other third parties relied on or otherwise engaged by Contractor, except to the extent such subcontractor's non-performance is itself the result of an Excusable Delay Event.

  • Upon the occurrence of any Excusable Delay Event that causes a delay in Contractor's performance of its obligations hereunder, an equitable adjustment shall be negotiated in the Statement of Work (Milestone Schedule), the Price and Payment Plan (Payment Milestone Schedule) and other portions of this Contract affected by the Excusable Delay Event; provided, however, Contractor acknowledges and agrees, there shall be no adjustment to the Purchase Price due to any Excusable Delay Event.

  • Subject to the other provisions of this clause the obligations of the Affected Party under this Agreement shall be suspended, to the extent that they are affected by the Excusable Delay Event, from the date the Affected Party serves a Suspension Notice in respect of that Excusable Delay Event until the cessation of the Excusable Delay Event.

  • If Contractor or City experiences an Excusable Delay Event, Contractor or City shall, within ten (10) days after first becoming aware of each such event, give written notice of the delay to the other party and describe any impact the “Excusable Delay” may have upon the Schedule.


More Definitions of Excusable Delay Event

Excusable Delay Event means a BC Hydro Delay, a Project Delay, a public protest (as described in Section 12.6 of this Schedule 2 [General Conditions]) or an event of Force Majeure that in each case: (i) causes a delay to the then current critical path for completion of the Work or an Interface Milestone; and (ii) occurs contemporaneously with a Contractor Delay that also causes a delay to the then current critical path for completion of the Work or an Interface Milestone.
View Source
Excusable Delay Event means a delay that results from: (1) an event described in Section 13 of this Agreement that directly impacts Comcast’s ability to achieve Final Completion of the Project; or (2) make-ready work that is not completed within six (6) months of Comcast's submission of a proper application for utility pole attachments.
View Source
Excusable Delay Event means any: fire, flood, earthquake, elements of nature or act of God; war, terrorism (both internal and external), acts of sabotage; inclement weather; shortage or delay in the availability of any goods, materials or plant and equipment required for the construction of the Development; delay from any Authority in issuing any Approvals; riot, civil disorder, rebellion or revolution; a strike, blockade, lockout or industrial action, dispute or disturbance of any kind (except where that circumstance relates to issues specific to the affected Party or its related bodies corporate (as that term is defined in the Corporations ▇▇▇ ▇▇▇▇ (Cth)); or other similar cause beyond the reasonable control of either Party, but in each case only if and to the extent that the non-performing Party is without fault in causing the default or delay, and the default or delay could not have been prevented by reasonable precautions and cannot reasonably be circumvented by the non-performing Party at its reasonable expense through the use of alternate sources, work around plans or other means.
View Source
Excusable Delay Event means any:
View Source

Related to Excusable Delay Event

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Excusable Delays mean delays arising without the fault or negligence of Lessor and Lessor's subcontractors and suppliers at any tier, and shall include, without limitation: (1) acts of God or of the public enemy, (2) acts of the United States of America in either its sovereign or contractual capacity, (3) acts of another contractor in the performance of a contract with the Government, (4) fires, (5) floods, (6) epidemics, (7) quarantine restrictions, (8) strikes, (9) freight embargoes, (10) unusually severe weather, or (11) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Lessor and any such subcontractor or supplier.

  • Delay Event means: (i) a tsunami, flood, cyclone, earthquake, bushfire or other act of nature; (ii) riot, civil commotion, war, invasion or a terrorist act; (iii) an imminent threat of an event in paragraphs (i) or (ii); or (iv) compliance with any lawful direction or order by a Government Agency; or (v) if clause 2.5 applies, the computer system operated by the ATO for the GST Withholding notifications referred to in clause 2.5(5)(c) is inoperative;

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.