APPLICANT’S RESPONSIBILITIES Sample Clauses
The "Applicant’s Responsibilities" clause defines the specific duties and obligations that the applicant must fulfill under the agreement. This may include providing accurate information, submitting required documentation, complying with deadlines, or adhering to certain standards or procedures set by the other party. By clearly outlining what is expected from the applicant, this clause ensures accountability and helps prevent misunderstandings or disputes regarding the applicant’s role in the contractual relationship.
POPULAR SAMPLE Copied 1 times
APPLICANT’S RESPONSIBILITIES that: Upon approval of application by the Lewis County Commissioners, applicant agrees
1. The project must be in progress within six (6) months of the date of this agreement or grant funds shall revert back to the Lewis County “Distressed Counties Fund.” For purposes of being “in progress,” the project must have proceeded beyond the initial planning stage, and into the implementation stages of the project. The Chehalis River Basin Flood Control Zone District shall promptly notify Lewis County in writing of any actual or anticipated event that is delaying or could delay achievement of any milestone or performance of any critical path activity of the project. A copy of this report shall also be placed in the file of the Economic Development Public Facilities Advisory Committee.
2. The Applicant must provide semi-annual progress report to the Lewis County Board of County Commissioners in order to ensure satisfactory completion of the project and proper expenditure of grant monies. The scope of project work is contained in the .09 application dated February 28, 2020, and is hereby incorporated by reference into this agreement, but is supplemented by this Amendment. Failure to provide progress reports or sufficient information may result in reversion to the “Distressed Counties Fund” of all or part of the funding balance. At such times as the Lewis County Board of Commissioners deems necessary for reasonable cause, the applicant shall permit the County to inspect and audit all pertinent books and records of the applicant or other persons or entities that have performed work in connection with or related to this funding. The audit may take place up to three years after completion of the project. The books and records are to be made available at reasonable times at such reasonable location as County selects. At Lewis County’s request, the applicant shall supply County with, or shall permit County to make a copy of, any books and records and any portion thereof.
3. Applicant has requested these County funds in order to advance engineering for continued development of the proposed flood retention facility, as well as for land acquisition and associated costs to bank properties that can potentially be used to mitigate for the proposed flood retention facility’s impacts, if the project is chosen. Failure to comply with the intent of this section may result in reversion to the “Distressed Counties Fund” of all or part of the funding balance. Funding to complete the fu...
APPLICANT’S RESPONSIBILITIES. Upon approval of application by the ▇▇▇▇▇ County Commissioners, applicant agrees that:
1. The project must be in progress within six (6) months of the date of this agreement or loan funds shall revert back to the ▇▇▇▇▇ County “Distressed Counties Fund.” For purposes of being “in progress,” the project must have proceeded beyond the initial planning stage and into the implementation stages of the project. The East ▇▇▇▇▇ County Public Development Authority shall promptly notify ▇▇▇▇▇ County in writing of any actual or anticipated event that is delaying or could delay achievement of any milestone or performance of any critical path activity of the project. A copy of this report shall also be placed in the file of the Economic Development Public Facilities Advisory Committee.
2. The Applicant must provide semi-annual progress report to the ▇▇▇▇▇ County Board of County Commissioners in order to ensure satisfactory completion of the project and proper expenditure of loan monies. The scope of project work is contained in the .09 application dated October 7, 2020, and is hereby incorporated by reference into this agreement. Failure to provide progress reports or sufficient information may result in reversion to the “Distressed Counties Fund” of all or part of the funding balance. At such times as the ▇▇▇▇▇ County Board of Commissioners deems necessary for reasonable cause, the applicant shall permit the County to inspect and audit all pertinent books and records of the applicant or other persons or entities that have performed work in connection with or related to this funding. The audit may take place up to three years after completion of the project. The books and records are to be made available at reasonable times at such reasonable location as County selects. At ▇▇▇▇▇ County’s request, the applicant shall supply County with, or shall permit County to make a copy of, any books and records and any portion thereof.
3. The ELCDPA has requested these County funds in order to make a semi-annual Craft3 loan payment. Failure to comply with the intent of this section may result in reversion to the “Distressed Counties Fund” of all or part of the funding balance. Funding to complete the full project as presented in the application must be confirmed and available prior to release of these funds. Failure to comply with this section may result in reversion to the “Distressed Counties Fund” of all or part of the funding balance.
4. The ELCDPA shall provide documented evide...
APPLICANT’S RESPONSIBILITIES. 3.1 The Applicants agree that all persons that have parental and/or legal guardianship responsibility for the Student must accept this Contract unless one of those persons can demonstrate in writing, either by evidence of a court order or other sufficient documentary evidence, to the satisfaction of the Principal, that he/she has sole legal responsibility for:
a) the education and Enrolment of the Student; and
b) payment of all Fees.
3.2 The Applicants agree that the College may provide information relating to the Student including but not limited to, reports, newsletters and information regarding College activities, to all persons who have legal parental responsibility for the Student, whether or not those persons have accepted this Contract, unless documentary evidence stating otherwise, that is to the satisfaction of the Principal, is provided to the College.
3.3 The Applicants will take responsibility to ensure the Student and the Applicants will uphold the reputation of the College which includes, but is not limited to, the prevention of what the College would deem as inappropriate references or images, whether or not related to the College or members of the College community, being uploaded, distributed or displayed on the internet, social media or other mediums. This responsibility extends beyond the period of time that the Student is enrolled at the College and beyond the termination of this Contract.
3.4 The Applicants agree that they will be responsible for any loss, damage or liability incurred by the College arising in connection with any failure by the Student to comply with Rules and Policies.
APPLICANT’S RESPONSIBILITIES. A bargaining unit member must submit her/his application for reappointment, tenure, or promotion to the department in accordance with the calendar and in the manner prescribed in this Agreement and department procedures, criteria, standards, and bylaws.
APPLICANT’S RESPONSIBILITIES. The Commission may request the Applicant modify the sign(s) when necessary to comply with changed standards that might be promulgated or adopted at the Applicant’s cost and Commission may request the Applicant to relocate the signs to accommodate the need to install signs the Commission, in its sole discretion, deems more appropriate at the Applicant’s cost. Should the Commission make either request, the Applicant shall comply with the Commission's request within 14 calendar days.
APPLICANT’S RESPONSIBILITIES. In the event you are compelled by any binding judgment, decree, order or award to make any payment under the Credit or to honor any Drafts or Documents as complying with the Credit, our obligations arising under this Agreement to reimburse you shall continue to apply or, if previously expired, shall be immediately restored, upon the rendering of any such judgment, decree, order or award, regardless of whether or not such judgment, decree, order or award shall be rendered, or any payment pursuant thereto shall be made, after the expiration of the Credit.
APPLICANT’S RESPONSIBILITIES. Take all cans and bottles with you when you leave. • Remove all decorations (including tacks, staples, tape, etc.) • All furniture or fixtures that are moved from the dining room must be put back before you leave. Table rounds, etc., must be returned to the tables after clean-up. Initial • You are responsible for supplying your own volunteers to move items. Initial
APPLICANT’S RESPONSIBILITIES. A. The Applicant will post a financial security (such as a surety bond, letter of credit, etc.) with the BLM in an amount sufficient to cover all costs associated with implementing the HPTP, as negotiated by the Applicant where they contract for services in support of this PA. Such costs should cover all aspects of the HPTP implementation and may include, but are not limited to, inventory; treatment; post-field analyses; research and report preparation; interim and summary reports preparation; the curation of Project documentation, samples, and artifact collections in a BLM-approved curation facility; and the repatriation and reburial of any human remains, sacred objects, or objects of cultural patrimony. The Applicant will post a financial security prior to commencing any work to implement the HPTP.
B. The security posted is subject to forfeiture if the Applicant does not complete tasks within the time period established by the treatment selected; provided, however, that the BLM and the Applicant may agree to extend any such time periods. The BLM will notify the Applicant that the security is subject to forfeiture and will allow the Applicant thirty (30) calendar days to respond before action is taken to forfeit the security.
C. The BLM will release the financial security, in whole or in part, as specific tasks are completed and accepted by the BLM.
APPLICANT’S RESPONSIBILITIES. APPLICANT shall comply with all laws and requirements set forth in Utah Code ▇▇▇. §§ 58-37f-101 through 801, and all rules and requirements set forth in Utah Administrative Code R156-37f-101 et seq. APPLICANT understands and acknowledges the criminal and civil penalties set forth in Utah Code ▇▇▇. § 58-37f-601 for unlawful access, use, or release of Database information.
APPLICANT’S RESPONSIBILITIES. When making an application to RRL of the type described in paragraph 3.2 above, RRL shall ensure that the Applicant shall:
(a) at the time as submitting the application to RRL, send a copy of the application to CRL; and
(b) specify in the application