Change Orders Requested by Owner Sample Clauses

The "Change Orders Requested by Owner" clause defines the process by which the owner of a project can request modifications to the original scope of work after the contract has been executed. Typically, this clause outlines the steps the owner must follow to initiate a change, such as submitting a written request, and describes how adjustments to the contract price, schedule, or deliverables will be handled. By establishing a clear procedure for managing changes, this clause helps prevent disputes and ensures that both parties understand how alterations to the project will be documented and compensated.
Change Orders Requested by Owner. Until Substantial Completion of Subproject 2, Owner shall be entitled to a Change Order upon request in accordance with this Section 6.1. A. If Owner submits to Contractor in writing a duly signed proposed Change Order, Contractor must respond to Owner, to the extent practicable, within thirty (30) Days with a written statement setting forth the effect, if any, which such proposed Change Order would have on the Contract Price, the Project Schedule, the Design Basis, the Payment Schedule, any of the Minimum Acceptance Criteria, Performance Guarantee or Guarantee Conditions, and/or any other obligation or potential liability of Contractor hereunder (collectively or individually, the “Changed Criteria”). The written statement shall be in the form of Schedule D-3, and shall include, to the extent practicable, all information required by Section 6.5B. Owner shall respond to Contractor’s written statement within fourteen (14) Business Days of receipt, responding to Contractor’s statement as to the effects of the proposed Change Order on the Changed Criteria. If it is not practicable for Contractor to provide all of the information required under this Section 6.1A to be submitted with such written statement within such thirty (30) Day period, Contractor shall provide Owner with as much information as practicable as well as a written explanation of the reason additional time is required. To the extent Contractor incurs costs exceeding Thirty Thousand U.S. Dollars (U.S.$30,000) (which costs shall be adequately documented and supported by Contractor) in responding to any one proposed Change Order, Contractor shall be reimbursed for such excess costs in responding to such Change Order within twenty-five (25) Days after Owner’s receipt of Contractor’s invoice therefor; provided that Contractor first gives Owner written notice of the estimate of the cost of such preparation before preparing the response, such estimate is in excess of Thirty Thousand U.S. Dollars (U.S.$30,000), Owner approves in writing the preparation of the response, and such proposed Change Order is not implemented. B. If the Parties agree on such Changed Criteria of the proposed Change Order (or modify such proposed Change Order so that the Parties agree on such Changed Criteria), the Parties shall execute such Change Order incorporating the Changed Criteria, which shall be in the form of Schedule D-1, and such Change Order shall become binding on the Parties, as part of this Agreement. C. If the Pa...
View SourceView Similar (29)
Change Orders Requested by Owner. 16 (a) Mutually-Agreed Upon Change Orders. Owner may, from time to time, order changes in the Services consisting of additions, deletions, or modifications, with one or more of the Contract Price, Payment Schedule, Time Schedule and Completion Dates being adjusted as applicable (collectively, the “Changed Criteria”). Such changes in the Services shall be authorized in writing using a written change order signed by Owner and Architect, which shall be in the form of Appendix I-1 (“Change Order”). 16
View Source
Change Orders Requested by Owner. 8.2.1 Owner shall have the right in its sole and absolute discretion to make changes in the Work (including changes which reduce the scope of Contractor’s Work hereunder). All such changes shall be made and documented in accordance with this Section 8.2 and shall be considered, for all purposes of this Agreement, as part of the Work. The adjustments to the Work, the Contract Price, the Milestones, the Payment Schedule, the Key Date Schedule, including the Guaranteed Substantial Completion Dates, or the Guaranteed Performance Levels, as described in this Section 8.2, shall be the sole adjustments to any of the terms and conditions of this Agreement as a result of the applicable Owner-initiated Change Order.
View Source

Related to Change Orders Requested by Owner

  • Change Order The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • Change Order Process 12.2.1 Contractor shall provide Notice to Owner as soon as practicable, but no later than five (5) Business Days, after the time when Contractor knows of the impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that will impact the Work. Failure to provide such Notice within ten (10) Business Days after the time when Contractor knows of the impact of any Force Majeure Event shall be deemed to be a waiver of the Contractor’s right to receive a Change Order with respect thereto. Such Notice shall, to the extent practicable, specify the estimated impact on the Target Price and/or the Project Schedule, as applicable, the impact upon the various portions of the Work occasioned by reason of such Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, and shall substantiate the foregoing to the satisfaction of Owner. In the event that Contractor does not know or is unable to specify with reasonable certainty the impact upon the Work at the time such Notice is to be delivered, Contractor shall instead provide Owner with a notice of a potential or anticipated impact of any Force Majeure Event, Owner Caused Delay or any other basis for a Change Order that could impact the Work, and shall thereafter provide Owner (and, if requested by Owner, the Independent Engineer) with periodic supplemental Notices during the period that the Force Majeure Event, Owner Caused Delay or any other basis for a Change Order, as applicable, continues, detailing any developments, progress or other relevant information of which Contractor is aware. To the extent Owner (in consultation with the Independent Engineer with respect to a Material Change) agrees with the Contractor’s determination of a Force Majeure Event or Owner Caused Delay or any other basis for a Change Order, as applicable, and the effects thereof, Owner shall notify Contractor of Owner’s acceptance. In the event Owner (in consultation with the Independent Engineer with respect to a Material Change) does not accept the Contractor’s findings, Owner or Contractor shall be permitted to dispute such Change Order in accordance with Article 36, and Contractor shall be paid for any Work performed in respect of such disputed Change Order as provided in Section 12.2.5. 12.2.2 As soon as practicable, and in any event within fifteen (15) Days (or such other period as is mutually agreed by Owner and Contractor) after receipt from Owner of a request for a change or Notice of Owner’s acceptance under Section 12.2.1, Contractor shall submit to Owner a proposal for implementing the change indicating the estimated change to the Target Price and/or the Project Schedule, as applicable. If Owner (having consulted with the Independent Engineer in the case of a Material Change) agrees that the Contractor’s proposal should be implemented, Owner (having consulted with the Independent Engineer in the case of a Material Change) shall issue a Change Order incorporating such proposal. Upon receiving such Change Order, Contractor shall diligently perform the change in accordance with the terms thereof. 12.2.3 Contractor’s proposal required pursuant to Section 12.2.2 shall consist of: (a) a detailed material take-off with supporting calculations in accordance with the pricing structure herein, for pricing the change, (b) revisions, if any, to the Drawings and Specifications, (c) a schedule for the work associated with the proposed change, (d) the effect, if any, to the Target Price and/or the Project Schedule, as applicable, (e) the effect, if any, of the change on the Work, including the Performance Tests and/or Demonstration Tests (or protocol therefor), (f) changes, if any, to any right, liability or obligation of a Party or any other provision hereof and (g) changes, if applicable, to any Applicable Deadline.

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • Notice to Contractor The Contractor is required to submit Certificates of Insurance acceptable to the State as evidence of insurance coverage requirements prior to commencing work under this Contract. Contractor shall not commence work under the contract until they have obtained all the insurance described below and the State has approved such insurance. Contractor shall maintain such insurance in force and effect throughout the term of this Contract, unless otherwise specified in this Contract The failure of the Contractor to provide a Certificate of Insurance, for the policies required under this Contract or renewals thereof, or failure of the insurance company to notify the State of the cancellation of policies required under this Contract shall not constitute a waiver by the State to the Contractor to provide such insurance. The State reserves the right to immediately terminate this Contract if the Contractor is not in compliance with the insurance requirements and retains all rights to pursue any legal remedies against the Contractor. All insurance policies must be open to inspection by the State, and copies of policies must be submitted to the State’s Authorized Representative upon written request.

  • Notice to Class Members 7.4.1 No later than three (3) business days after receipt of the Class Data, the Administrator shall notify Class Counsel that the list has been received and state the number of Class Members, PAGA Members, Workweeks, and Pay Periods in the Class Data. 7.4.2 Using best efforts to perform as soon as possible, and in no event later than 14 days after receiving the Class Data, the Administrator will send to all Class Members identified in the Class Data, via first-class United States Postal Service (“USPS”) mail, the Class Notice with Spanish translation, if applicable substantially in the form attached to this Agreement as Exhibit A. The first page of the Class Notice shall prominently estimate the dollar amounts of any Individual Class Payment and/or Individual PAGA Payment payable to the Class Member, and the number of Workweeks and PAGA Pay Periods (if applicable) used to calculate these amounts. Before mailing Class Notices, the Administrator shall update Class Member addresses using the National Change of Address database. 7.4.3 Not later than 3 business days after the Administrator’s receipt of any Class Notice returned by the USPS as undelivered, the Administrator shall re-mail the Class Notice using any forwarding address provided by the USPS. If the USPS does not provide a forwarding address, the Administrator shall conduct a Class Member Address Search, and re-mail the Class Notice to the most current address obtained. The Administrator has no obligation to make further attempts to locate or send Class Notice to Class Members whose Class Notice is returned by the USPS a second time. 7.4.4 The deadlines for Class Members’ written objections, Challenges to Workweeks and/or Pay Periods, and Requests for Exclusion will be extended an additional 14 days beyond the 60 days otherwise provided in the Class Notice for all Class Members whose notice is re-mailed. The Administrator will inform the Class Member of the extended deadline with the re-mailed Class Notice. 7.4.5 If the Administrator, Defendant or Class Counsel is contacted by or otherwise discovers any persons who believe they should have been included in the Class Data and should have received Class Notice, the Parties will expeditiously meet and confer in person or by telephone, and in good faith in an effort to agree on whether to include them as Class Members. If the Parties agree, such persons will be Class Members entitled to the same rights as other Class Members, and the Administrator will send, via email or overnight delivery, a Class Notice requiring them to exercise options under this Agreement not later than 14 days after receipt of Class Notice, or the deadline dates in the Class Notice, which ever are later.