DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES Sample Clauses

The "Design-Builder's Duties and Responsibilities" clause defines the obligations and expectations placed on the design-builder throughout the project. It typically outlines the scope of services the design-builder must provide, such as preparing design documents, obtaining necessary approvals, and coordinating construction activities. This clause ensures that the design-builder is accountable for both the design and construction phases, clarifying roles and reducing the risk of misunderstandings or gaps in project delivery.
DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES. 5.1 General Scope of Services. 5.1.1 For every Work Order Package awarded to the Design- Builder, the Design-Builder shall furnish all design and other Services, provide all equipment and materials and undertake all efforts to design, construct, and perform the Work in accordance with the requirements of the applicable Work Order Package, Contract Documents, all Governmental Approvals, the City- approved Design and Construction Documents, all Applicable Laws, and all other applicable safety, environmental and other requirements taking into account the constraints affecting the Site. For each Work Order Package awarded to Design- Builder, the Design-Builder shall furnish the design and other Services set forth in the Work Order Package, provide all materials and shall construct the Work Order Package project as designed, all (a) in accordance with all professional engineering principles and construction practices generally accepted as standards of the industry in the State of California, (b) in a good and workmanlike manner, (c) free from defects and (d) in accordance with the terms and conditions set forth in the Contract Documents on a Turnkey Contract Basis. Except as otherwise specifically provided in this Contract, all materials, services and efforts necessary to achieve Substantial Completion and elements thereof on or before the Milestone Dates provided in the Contract Documents shall be Design-Builder's sole responsibility. The costs of all such materials, services and efforts are included in the Work Order Package Price. 5.1.2 The scope of Work Order Package to be provided by Design-Builder is set forth therein, including applicable Contract Documents as more particularly described in the Design and Performance Criteria which includes preliminary drawings and specifications. 5.1.3 The Design-Builder, whether a general contractor, construction company or joint venture, shall hold valid California Class “A” General Engineering Contractor and Class "C" licenses from the Effective Date , and shall maintain the licenses at all times during the Term. 5.1.4 All Subcontractors shall hold the appropriate California C- specialty, A-general engineering contractor license or engineering license, at the time of award of a Work Order Package and shall maintain the licenses at all times during performance of the Work. 5.1.5 Design-Builder and all Subcontractors shall have a valid Department of Industrial Relations Registration Number at all times during performan...
View SourceView Similar (2)
DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES. The enumeration of specific tasks within this Article shall not limit the actual responsibilities of the DESIGN‐BUILDER to complete the PROJECT as required within this AGREEMENT and the Final Construction Documents and the responsibility to perform all tasks reasonably required to accomplish those requirements.
View Source
DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES. ‌ 3.1 Performance of Work.‌ 3.1.1 Design/Builder shall be responsible for achieving the Occupancy and Final Completion Milestones dates in the Project Milestone Schedule as shown in Exhibit A. The schedule may be modified from time to time pursuant to the provisions of the Contract Documents. 3.2 Design/Builder’s Responsibilities.‌ 3.2.1 Design/Builder further agrees to design and construct the Project in consideration for the STA’s payment of the Contract Amount of $ which may be adjusted pursuant to the provisions of this Agreement. The duties and responsibilities include, but are not limited to, the following tasks:
View Source
DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES. 3.1. Performance of Work. 3.1.1. Design/Builder shall be responsible for achieving the Occupancy and Final Completion Milestones dates in the Project Milestone Schedule as shown in Exhibit A. The schedule may be modified from time to time pursuant to the provisions of the Contract Documents.
View Source
DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES. 5.1 General Scope of Services. 5.1.1 Furnish all design and other Services, provide all materials and undertake all efforts necessary or appropriate to construct the Project in accordance with the requirements of the Contract Documents, all Governmental Approvals, the approved Construction Documents, all Applicable Law, and all other applicable safety, environmental and other requirements taking into account the constraints affecting the Project site. Design-Builder shall furnish the design and other Services, provide all material of the Project and shall construct the Project as designed, in accordance with all professional engineering principles and construction practices generally accepted as standards of the industry in the State of California, in a good and workmanlike manner, free from defects and in accordance with the terms and conditions set forth in the Contract Documents. Except as otherwise specifically provided in this Contract, all materials, services and efforts necessary to achieve Substantial Completion of the Project and elements thereof on or before the Milestone deadlines provided in the Contract Documents shall be Design-Builder's sole responsibility. The costs of all such materials, services and efforts are included in the Contract Price. 5.1.2 The scope of Services to be provided by Design-Builder is set forth in the Contract Documents as more particularly described in the Design and Performance Criteria, Preliminary Drawings and Technical Specifications. 5.1.3 The Design-Builder shall hold and maintain a valid California Class A-General Engineering Contractor license at all times during performance of the Work. 5.1.4 All Subcontractors shall hold and maintain the appropriate California C-specialty license, A-general engineering contractor license or engineering license, indicated on the Subcontractor List and Declaration at all times during performance of the Work. 5.1.5 The Design-Builder and all Subcontractors, including unlisted Subcontractors shall obtain a Business Tax Registration from the City of Burbank License Division, ▇▇▇ ▇. ▇▇▇▇▇ ▇▇▇▇▇▇, ▇▇▇▇▇▇▇, ▇▇ ▇▇▇▇▇, prior to commencement of Work.
View Source
DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES. 8 5.1 General Scope of Services 8 5.2 Before Starting Work 8 5.3 Initial Conference. 9 5.4 Evaluation of Preliminary Submittals 9 5.5 Key Personnel 9 5.6 Design Phase Services 10 5.7 Construction Phase Services 12 5.8 Field Testing 13 5.9 General Duties and Responsibilities 14
View Source
DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES. 4.1 GENERAL DUTIES AND OBLIGATIONS OF DESIGN-BUILDER RELATED TO ENTIRE WORK. 4.1.1 CITY has retained DESIGN-BUILDER to provide the Work described herein. Since CITY has entrusted the Work to the DESIGN-BUILDER, DESIGN- BUILDER shall use its professional expertise to protect the interest of the CITY at all times. The quality of DESIGN-BUILDER’s work shall be consistent with the requirements of this Contract and with prevailing industry standards. DESIGN-BUILDER shall ensure that its fees charged for the Work are fair, reasonable and consistent with fees charged locally for similar work.
View Source
DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES 
View Source

Related to DESIGN-BUILDER'S DUTIES AND RESPONSIBILITIES

  • Duties and Responsibilities (a) The Auction Agent is acting solely as agent for the Company hereunder and owes no fiduciary duties to any other Person by reason of this Agreement. (b) The Auction Agent undertakes to perform such duties and only such duties as are set forth specifically in this Agreement, and no implied covenants or obligations shall be read into this Agreement against the Auction Agent. (c) In the absence of bad faith or negligence on its part, the Auction Agent shall not be liable for any action taken, suffered or omitted by it, or for any error of judgment made by it in the performance of its duties under this Agreement. The Auction Agent shall not be liable for any error of judgment made in good faith unless the Auction Agent shall have been negligent in ascertaining (or failing to ascertain) the pertinent facts.

  • General Duties and Responsibilities 1. Responsibilities under the General Conditions of the Contract for Construction: In addition to the responsibilities herein set forth, Consulting Engineer/Architect agrees to be responsible for those matters identified in the General Conditions as being responsibilities of the Consulting Engineer/Architect. Consulting Engineer/Architect specifically acknowledges receipt of a copy of the General Conditions and acceptance of the responsibilities as set forth therein.