Notice of Commencement of Work Sample Clauses

Notice of Commencement of Work. At least 2 days before commencing any work the Owner must notify Council of the intention to commence work. This notice must be given by providing the Notice of Commencement of Building or Subdivision work to Council. This form will be attached to documentation sent to the owner where Council is appointed as the Principal Certifier. As Principal Certifier, Council will check that building work complies with the Development Consent, Construction Certificate, the National Construction Code Series (NCC), relevant Australian Standards and environmental standards of construction. As Principal Certifier Council will endeavour to:

Notice of Commencement of Work. If the supervisor fails to issue the commencement notice within 90 days from the planned commencement date due to the employer's reasons, the contractor has the right to request a price adjustment or terminate the contract.

Notice of Commencement of Work. The Association agrees to give the Plaintiffs no less than sixty (60) days’ advance notice of when construction of the Wall will begin. At the time such notice is given, the Association shall inform the Plaintiffs whether the Association will require access through the 115 Property in order to perform the work, and the Plaintiffs shall grant such reasonable access. If the Association requires access across the 115 Property to perform the work, the Association shall not damage any structures or fixtures on the 115 Property, and shall restore the original condition of the 115 Property at the Association’s expense following completion of the work. Plaintiffs agree to give the Association no less than sixty (60) days’ advance notice of when any construction on the 115 Property will begin that may interfere with the Association’s construction of the Wall.

Notice of Commencement of Work. FLAGGING

Notice of Commencement of Work. If an emergency should arise requiring immediate attention, Licensee shall provide as much notice as practicable to Licensor before commencing any work. In all other situations, Licensee shall notify Licensor at least 10 days (or such other time as Licensor may allow) in advance of the commencement of any work upon the Property in connection with the construction, maintenance, repair, renewal, modification, relocation, reconstruction, or removal of the Pipeline. All such work shall be prosecuted diligently to completion.

Notice of Commencement of Work. TO: Building Architect Royal Summit Owners, Inc. Mr. ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇/▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇ ▇▇▇▇, ▇.▇. ▇▇▇▇▇ Building Engineer Tudor Realty Services Corp. ▇▇. ▇▇▇ ▇▇▇▇ ▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇, 4th Floor New York, N.Y. 10003 Dear , Please take notice that the undersigned wishes to install equipment and to make alterations in Apartment at ▇▇▇/▇▇▇ ▇▇▇▇ ▇▇▇▇ ▇▇▇▇▇▇ (▇▇▇ “Work”). The Work is scheduled to commence on ,(the “Commencement Date”) and is projected to be completed on or before (the “Projected Completion Date”). The undersigned shall indemnify and hold harmless Royal Summit, its employees, its officers and directors, the recipients of this notice and all other shareholders and residents of Royal Summit against any damages suffered to persons or property as a result of the Work. The undersigned shall reimburse all of the above-mentioned persons for any losses, costs, fines, fees and expenses (including, without limitation, reason able attorney's fees and disbursements) incurred by them as a result of the Work or failure by the undersigned or his contractors to comply with the alteration agreement between Royal Summit and the undersigned or any applicable law, rule or regulation, or in the defense of any suit, action, claim or violation in connection with the Work. Signature: Tenant-Shareholder Print Name: Tenant-Shareholder & Apt. # A ND CONNECTION TO BUILDING’S

Notice of Commencement of Work. The Grantee shall notify the Grantor at lease twenty-four (24) hours in advance of the commencement of any work in the Easement Area in connection with the replacement and/or repair of the irrigation ditch banks. The Grantee shall not be obligated to provide notice of Grantee’s entries into and work within the Easement Area which is periodically undertaken for the purpose of operation and maintenance of the ditch or the Easement Area and which does not involve disturbance of the irrigation ditch banks. In the event of an unexpected and unanticipated situations where it may be impractical to provide the Grantor with advance notice, the Grantee may commence with any necessary work and the Grantee shall contact Grantor regarding the nature of the work at the earliest opportunity.

Notice of Commencement of Work. The Employer shall obtain the permission required for the construction of the project in accordance with the law. After the consent of the Employer, the notice of commencement of work issued by the Supervisor shall comply with the law. The Supervisor shall issue a notice of commencement to the Contractor 7 days before the planned start date, and the construction period shall start from the date of commencement as specified in the notice of commencement of work. Except as otherwise stipulated in the special contract terms, if the Supervisor fails to issue the notice of commencement of work within 90 days from the date of the commencement of the project for any reason caused for the Employer, the Contractor has the right to request the price adjustment or terminate the contract. The Employer shall bear the resulting increase in costs and/or delays in the duration of the work.

Notice of Commencement of Work. Company shall provide the City and the Foundation with prior notice of the date on which the Company intends to commence use of the Designated Roads for the Activities. Notice for purposes of this Section must be provided by both telephone and e-mail.