Schedule and Reports Clause Samples

Schedule and Reports. Promptly after the award of the Contract, the Contractor shall present a construction schedule in a form satisfactory to the Agency. The schedule shall not exceed the time limits current under the Contract Documents. The Contractor shall update the schedule at appropriate intervals as required by the conditions of the Work, showing the actual progress of the Work and adjustment in completion dates. If the Work falls behind schedule, the Contractor shall present a plan for completion of the Work by the scheduled date for completion.
View SourceView Similar (9)
Schedule and Reports. The Design-Builder shall prepare and provide the Owner with a work sequence schedule for Design-Build Work in accordance with Appendix 4 (General Design-Build Work Requirements). Throughout the Design-Build Period, the Design- Builder shall submit to the Owner and the Owner’s Representative a monthly progress report and schedule including among other things an update of the work sequence schedule in accordance with the requirements of Appendix 6 (Design-Build Work Review Procedures). The Design- Builder agrees that the Design-Builder’s submission of the monthly progress schedule and report (or any revised progress schedule and report) is for the Owner’s and the Owner’s information only. The Design-Builder’s submission of the monthly progress schedule and report shall not limit or otherwise affect the Design-Builder’s obligations to achieve Acceptance by the Scheduled Acceptance Date. The Owner’s acceptance of the monthly progress schedule and report (or any revised progress schedule and report) shall not bind the Owner in any manner. Thus, the Owner’s receipt and review of the monthly progress schedule and report (or any revised monthly progress schedule and report) shall not imply Owner approval or consent to any of the matters set forth therein.
View SourceView Similar (2)
Schedule and Reports. The DBOM Contractor shall prepare and provide the BWS with the “critical path method” Project Schedule for the Design-Build Work in accordance with Schedule 7 (Progress Schedule Requirements). Throughout the Design-Build Period, the DBOM Contractor shall submit to the BWS and the Project Manager Monthly Progress Reports, which shall include updates to the Project Schedule, in accordance with the requirements set forth in subsection 4.8(A) (Design-Build Period Monthly Progress Reports) and Schedule 7 (Progress Schedule Requirements). The DBOM Contractor agrees that the DBOM Contractor’s submission of the Monthly Progress Report and updated Project Schedule (or any revised Monthly Progress Report and updated Project Schedule) is for the BWS’s and the Project Manager’s information only and shall not limit or otherwise affect the DBOM Contractor’s obligations to achieve Acceptance by the Scheduled Acceptance Date. The BWS’s and the Project Manager’s receipt of the Monthly Progress Report and updated Project Schedule (or any revised Monthly Progress Report and updated Project Schedule) shall not bind the BWS in any manner. Thus, the BWS’s and the Project Manager’s receipt of the Monthly Progress Report and updated Project Schedule (or any revised Monthly Progress Report and updated Project Schedule) shall not imply BWS approval or consent to any of the matters set forth therein. Notwithstanding any of the foregoing, the DBOM Contractor acknowledges and agrees that it has a material obligation to provide the BWS with, and to update, maintain and revise, the critical path Project Schedule for the performance of the Design-Build Work throughout the Design-Build Period in accordance with the Contract Standards.
View Source
Schedule and Reports. Promptly after the Agency issues a Job Order, the Contractor shall present a construction schedule in a form satisfactory to the Agency. At intervals agreed upon in the Job Order, the Contractor shall update the schedule showing the actual progress of the work and adjustment in completion dates. If the work falls behind schedule, the Contractor shall present a plan for completion of the work by the scheduled date for completion.
View Source

Related to Schedule and Reports

  • Notice and Reports The request for the issuance of a Letter of Credit shall be submitted to the Issuing Lender at least five (5) Business Days prior to the requested date of issuance. The Issuing Lender will promptly upon request provide to the Administrative Agent for dissemination to the Revolving Lenders a detailed report specifying the Letters of Credit which are then issued and outstanding and any activity with respect thereto which may have occurred since the date of any prior report, and including therein, among other things, the account party, the beneficiary, the face amount, expiry date as well as any payments or expirations which may have occurred. The Issuing Lender will further provide to the Administrative Agent promptly upon request copies of the Letters of Credit. The Issuing Lender will provide to the Administrative Agent promptly upon request a summary report of the nature and extent of LOC Obligations then outstanding.

  • Filings and Reports (a) Each year during the term of the Fee Agreement, the Company and any Sponsor Affiliates shall deliver to the County, the County Auditor, the County Assessor and the County Treasurer a copy of their most recent annual filings with the Department with respect to the Project, not later than thirty (30) days following delivery thereof to the Department. (b) The Company shall cause a copy of this Fee Agreement, as well as a copy of the completed Form PT-443 of the Department, to be filed with the County Auditor and the County Assessor, and to their counterparts in the partner county to the MCIP Agreement, the County Administrator and the Department within thirty (30) days after the date of execution and delivery of this Fee Agreement by all parties hereto. (c) Each of the Company and any Sponsor Affiliates agree to maintain complete books and records accounting for the acquisition, financing, construction, and operation of the Project. Such books and records shall (i) permit ready identification of the various Phases and components thereof; (ii) confirm the dates on which each Phase was placed in service; and (iii) include copies of all filings made by the Company and any such Sponsor Affiliates in accordance with Section 3.03(a) or (b) above with respect to property placed in service as part of the Project.

  • STATEMENTS AND REPORTS Section 4.01 Distributions................................................. Section 4.02

  • Payments and Reports All payments and reports due hereunder shall be made on or before the day such payments and reports are due. Nothing in this paragraph shall be construed to extend the expiration of the primary term hereof. Oil royalty payments and supporting documents shall be submitted prior to the last day of the month following each month's sale of production, and gas royalty payments and supporting documents shall be submitted prior to the last day of the second month following each month's sale of production. All payments shall be made by cash, check, certified check, or money order. Payment having restrictions, qualifications, or encumbrances of any kind whatsoever shall not be accepted by Lessor. A penalty for a late payment shall be charged as set forth in the PENALTIES paragraph herein.

  • Access and Reports (a) The Company shall afford to Parent and its Representatives reasonable access during normal business hours, throughout the period prior to the earlier of the Effective Time and the Termination Date, to its and its Subsidiaries’ officers, employees, properties, contracts, commitments, books and records and any report, schedule or other document filed or received by it pursuant to the requirements of applicable Laws and shall furnish Parent with financial, operating and other data and information as Parent, through its respective officers, employees or other authorized Representatives may from time to time reasonably request in writing. (b) Notwithstanding the foregoing, the Company shall not be required to afford access pursuant to Section 7.05(a) if such access would unreasonably disrupt the operations of the Company or any of its Subsidiaries or would cause a violation of any agreement to which the Company or any of its Subsidiaries is a party, nor shall Parent, any of its Representatives or the Financing Sources be permitted to perform any onsite procedure (including any onsite environmental study) with respect to any property of the Company or any of its Subsidiaries. (c) This Section 7.05 shall not require the Company or its Subsidiaries to permit any access, or to disclose any information that, in the reasonable, good faith judgment (after consultation with counsel) of the Company, is likely to result in any violation of any Law or cause any privilege (including attorney-client privilege) that the Company or its Subsidiaries would be entitled to assert to be undermined with respect to such information and such undermining of such privilege could in the Company’s reasonable, good faith judgment (after consultation with counsel) adversely affect in any material respect the Company’s position in any pending litigation; provided, that , the parties hereto shall cooperate in seeking to find a way to allow disclosure of such information to the extent doing so (i) would not (in the good faith belief of the Company (after consultation with counsel)) be reasonably likely to result in the violation of any such Law or be likely to cause such privilege to be undermined with respect to such information or (ii) could reasonably (in the good faith belief of the Company (after consultation with counsel)) be managed through the use of customary “clean-room” arrangements.