Timing of Services Clause Samples
The "Timing of Services" clause defines when and how services under the agreement are to be performed. It typically specifies start and end dates, deadlines for deliverables, or schedules for ongoing work, ensuring both parties understand the expected timeline. By clearly outlining these timeframes, the clause helps prevent misunderstandings and disputes about service delivery, ensuring that obligations are met in a timely manner.
POPULAR SAMPLE Copied 7 times
Timing of Services. Consultant will perform the services in a timely manner; however, if during their performance, for reasons beyond the control of the Consultant, protracted delays occur, the parties agree that they will negotiate in writing an equitable adjustment of time and compensation, taking into consideration the impact of such delays.
Timing of Services. ECS will make every effort to provide timely delivery of Service. The Buyer acknowledges Service times can be impacted by many factors, and not all requests for Service can be delivered the same day. If emergency requests are made, or if requests are made outside of Standard Service hours, additional charges may apply pursuant to Section 2b.
Timing of Services. FCCS may exercise its own reasonable judgment, within the parameters set forth herein and in compliance with state regulations, as to the time and manner in which it performs the services required hereunder. Additionally, FCCS will be held to a standard of like administrators performing like services for customers such as the Client.
Timing of Services. All tutoring services shall be provided by the Teacher at such times and according to such schedule as may be specified by the School or the District or, absent such specification, at times which are mutually convenient to the Teacher and the students tutored, but no such services shall be provided during school hours on any day on which classes are in session at the School.
Timing of Services. CCMSI may exercise its own judgment, within the parameters set forth herein, as to the time and manner in which it performs the services required hereunder.
Timing of Services. CONSULTANT will perform the Services in a timely manner according to Exhibit 2. However, if during their performance, for reasons beyond the control of the CONSULTANT, delays occur, the parties agree that they will negotiate in writing an equitable adjustment of time and compensation, taking in to consideration the impact of such delays.
Timing of Services. Any Management Services provided by Colt Defense shall be performed in a reasonably prompt manner by the staff group that performed such services for CMC prior to the date of this Agreement, subject to the availability of personnel.
Timing of Services. CONSULTANT will perform the Services according to Exhibit 2. However, if during their performance, for reasons beyond the control of the CONSULTANT, delays occur, the parties agree that they will negotiate in writing an equitable adjustment of time and compensation, taking in to consideration the impact of such delays. CONSULTANT will endeavor to start its services on the anticipated start date and continue to endeavor to complete its services according to the schedule indicated in Exhibit 2. The start date, completion date and any milestone for project delivery are approximate only and CONSULTANT reserves the right to adjust its schedule and all of those dates at its sole discretion for delays caused by the CLIENT, Owner or third parties.
Timing of Services. We will use commercially reasonable efforts to deliver Services in a timely manner; however, We cannot guarantee that We can provide any Service by any desired deadline, as there may be circumstances beyond Our control.
Timing of Services. In normal circumstances, JCI will (a) initiate its Preventive Maintenance services with prior notification to the Project Representative, and (b) initiate remote diagnostics and notify the Project Representative by the next business day after JCI’s determination that the System has a Performance Shortfall or is experiencing a monitoring/connectivity issue.