Contract Time Schedule Sample Clauses

The Contract Time Schedule clause defines the timeline within which the parties must complete their contractual obligations. It typically outlines key milestones, deadlines for deliverables, and the overall project completion date, often including provisions for extensions or adjustments due to unforeseen circumstances. This clause ensures that all parties are aware of and adhere to agreed-upon timeframes, helping to manage expectations and reduce the risk of delays or disputes over project timing.
POPULAR SAMPLE Copied 1 times
Contract Time Schedule. The “Contract Time Schedule” is defined in Article 6.1 of this Agreement.
View SourceView Similar (2)
Contract Time Schedule. Contractor shall put forth a good faith effort to ensure that the Work will be prosecuted by Contractor in accord with the schedule set forth in Exhibit B hereto (the “Contract Time Schedule”) and upon progress schedules mutually agreed upon with Owner.
View SourceView Similar (2)
Contract Time Schedule. 5.1 The Work to be performed under this Agreement shall commence on or about June 1, 2007 and shall reach Final Completion on or about November 30, 2008. All dates in this article are subject to Owner providing proof of financial commitment from its lender and equity funding for the entire contract value, entering an EPC contract with the Contractor and paying a down payment to the Contractor by June 1, 2007. At that point, concentrated detailed engineering work will begin by Bratney Company and Cimbria-Sket. (“Beginning of Performance”). Dates in this section will be adjusted earlier or later based on the June 1, 2007 target for “Beginning of Performance”, but not necessarily on a day-for-day basis subject to mutual agreement of both parties. Any delay caused by Owner due to the delay in construction or operating permit receipts or raw material and utilities (water, Power, natural gas) availability will also extend dates in this article and not necessarily on a day for day basis subject to mutual agreement of both parties. Guaranteed Max Price Revised 06/18/2007 5.2 The work in this Agreement will occur and reach several milestones prior to Final Completion Status. Namely: - Mechanical Completion - Commissioning Completion - Operational Completion - Final Completion
View SourceView Similar (2)
Contract Time Schedule. 4.1 The Work to be performed under this Agreement shall be commenced within ten
View Source
Contract Time Schedule. 5.1 The Work to be performed under this Agreement shall be commenced on or about One Week from receipt of Building Permit and Owners Authorization to proceed with the work and shall be substantially completed on or about 180 Calendar Days from the start date. 5.2 The Date of Substantial Completion of the Project or a designated portion thereof is the date when construction is sufficiently complete in accordance with the Drawings and Specifications so the Owner can occupy or utilize the Project or designated portion thereof for the use for which it is intended. Warranties called for by this Agreement or by the Drawings and Specifications shall commence on the Date of Substantial Completion of the Project or designated portion thereof. This date shall be established by a Certificate of Substantial Completion signed by the Owner and Contractor and shall state their respective responsibilities for security, maintenance, heat, utilities, damage to the Work and insurance. This Certificate shall also list the items to be completed or corrected and fix the time for their completion and correction. 5.3 If the Contractor is delayed at any time in the progress of the Project by any act or neglect of the Owner or by any separate contractor employed by the Owner, or by changes ordered in the Project, or by labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, or any cause beyond the Contractor’s control, or a delay authorized by the Owner pending arbitration, then the Date of Substantial Completion shall be extended by Change Order for the period of time caused by such delay.
View Source
Contract Time Schedule. 5.1 Schedule - The services and work to be performed under this Contract shall be in general accordance with the Contract Time Schedule attached hereto as Schedule 1. 5.2 Initial Time of Completion – as established in the preliminary project schedule following are the milestone completion dates for the Project: 5.2.1 Start of Construction [DATE] 5.2.2 Final Completion [DATE] 5.3 Revised Time of Completion - At the time a Guaranteed Maximum Price is fixed, as provided for in Article 6, a new Revised Time of Completion shall also be established.
View Source
Contract Time Schedule. 5.1 The Project to be designed and constructed and the Work to be performed under this Agreement shall be commenced on or about December 30, 1996 and shall be substantially completed no later than April 1, 1998 ("Date of Substantial Completion" or "Start-up"). The Project and Work to be performed under this Agreement shall be completed so as to allow Owner to commence commercial operation of the Project on or before June 1, 1998 ("Final Completion Date"). 5.2 The portion of the Project to be performed under Phase 1 of this Agreement is anticipated to commence on December 30, 1996 and be completed on or before February 28, 1997. The portion of the Project to be performed under Phase 2 of this Agreement is anticipated to commence on or about March 1, 1997 and to be completed on or about May 30, 1997. In order to meet the Date of Substantial Completion and the Final Completion Date, the Work to be performed under Phase 3 of this Agreement relating to procurement and site work is anticipated to commence on or about April 1, 1997, and relating to erection-civil to commence on or about June 1, 1997. For that purpose and with respect to Phase 3, Owner may give Contractor a limited Notice to Proceed with all or part of procurement, site work and erection-civil, provided that Owner's power to terminate this Agreement pursuant to Article 2.1.4 shall continue until completion of Phase 2.
View Source
Contract Time Schedule 
View SourceView Similar (4)

Related to Contract Time Schedule

  • Time Schedule 4.1. A project schedule is included in Appendix A. 4.2. Any delay of services or change in sequence of tasks must be approved in writing by Delaware. 4.3. In the event that Vendor fails to complete the project or any phase thereof within the time specified in the Contract, or with such additional time as may be granted in writing by Delaware, or fails to prosecute the work, or any separable part thereof, with such diligence as will insure its completion within the time specified in this Agreement or any extensions thereof, Delaware shall suspend the payments scheduled as set forth in Appendix A.

  • Part-time Scheduling Subject to Section B of this Article, the Employer and the Association endorse the principle that less than full time equivalent ("FTE") positions shall, within reason, be expected to work a biweekly work period that equates to an eighty (80) hour work period multiplied by the position's FTE. (e.g., 80 hours @ .75 = 60 hours). It is further understood by both parties that ASF Members assigned to less than a FTE position may be required, during the peak work periods, to exceed their normal biweekly work period. FLSA non-exempt ASF Members who work a part-time schedule will earn overtime for hours worked in excess of forty (40) in a work week. The Employer agrees to review any ASF position that is less than one (1) FTE if the Association can demonstrate that the position has regularly been required to work a work period that substantially exceeds the normal work period as defined above, and adjust the FTE of the respective position as deemed appropriate by the Employer.

  • Contract Time The period of time established for completion of the Project by the Contract Documents. Contract Time commences upon the date specified in the Proceed Order and ends upon the Material Completion and Occupancy Date, as it may be amended.

  • Contract Schedule The information set forth in the Contract Schedule is true and correct.

  • Contract Times The number of days or the dates stated in the Agreement to: (i) achieve Substantial Completion; and (ii) complete the Work so that it is ready for final payment as evidenced by Architect's or Owner’s representative’s written recommendation of final payment.