Specifications and Drawings for Construction Sample Clauses
The "Specifications and Drawings for Construction" clause defines the requirement that all construction work must adhere to the detailed plans and technical documents provided by the project owner or architect. In practice, this means contractors are obligated to follow the precise measurements, materials, and methods outlined in the specifications and drawings, and any deviations typically require formal approval. This clause ensures that the finished construction meets the intended design and quality standards, reducing the risk of misunderstandings or disputes over the scope and execution of the work.
Specifications and Drawings for Construction. (a) The Contractor shall keep on the work site a copy of the drawings and specifications and shall at all times give the Contracting Officer access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter shall be requirements, the Contractor shall describe such variations in writing, separate from the drawings, at the time of submission. If the Architect approves any such variation and the Contracting Officer concurs, the Contracting Officer shall issue an appropriate modification to the contract, except that, if the variation is minor or does not involve a change in price or in time of performance, a modification need not be issued.
(g) It shall be the responsibility of the Contractor to make timely requests of the PHA for such large scale and full size drawings, color schemes, and other additional information, not already in his possession, which shall be required in the planning and production of the work. Such requests may be submitted as the need arises, but each such request shall be filed in ample time to permit appropriate action to be taken by all parties involved so as to avoid delay.
(h) The Contractor shall submit to the Contracting Officer for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. Three sets (unless otherwise indicated) of all shop drawings, will be retained by the PHA and one set will be returned to the Contractor. As required by the Contracting Officer, the Contractor, upon completing the work under this contract, shall furnish a complete set of all shop drawings as finally approved. These drawings shall show all changes and revisions machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer’s approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at t...
Specifications and Drawings for Construction. (a) The Contractor shall keep on the work site a copy of the drawings and specifications and shall at all times give the Contracting Officer access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter shall be promptly make a determination in writing. Any adjustment by the Contractor without such a determination shall be at its own risk and expense. The Contracting Officer shall furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided.
(b) Wherever in the specifications or upon the drawings the words “directed”, “required”, “ordered”, “designated”, “prescribed”, or words of like import are used, it shall be understood that the “direction”, “requirement”, “order”, “designation”, or “prescription”, of the Contracting Officer is intended and similarly the words “approved”, “acceptable”, “satisfactory”, or words of like import shall mean “approved by”, or “acceptable to”, or “satisfactory to” the Contracting Officer, unless otherwise expressly stated.
(c) Where “as shown” “as indicated”, “as detailed”, or words of similar import are used, it shall be understood that the reference is made to the drawings accompanying this contract unless stated otherwise. The word “provided” as used herein shall be understood to mean “provide complete in place” that is “furnished and installed”.
Specifications and Drawings for Construction. (a) Seller shall be furnished the number of drawings and specifications specified in Division One at no cost.
(b) Seller shall keep on the work site a copy of the drawings and specifications and shall at all times give Company access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. Within the specifications, Division One (the "Special Conditions") shall govern. In case of discrepancy in the figures, in the drawings, or in the remainder of the specifications, the matter shall be promptly submitted to the Construction Engineer and the Subcontract Administrator, who shall promptly make a determination in writing. Any adjustment by Seller without such a determination shall be at its own risk and expense. Company shall furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided.
(1) The drawings and specifications incorporated into this Agreement are intended to include everything requisite and
(2) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve Seller from performing such omitted or misdescribed details of the work, but they shall be performed as if fully and correctly set forth and described in the drawings and specifications.
(3) The specifications and drawings may identify and list quantities of items to be furnished and installed by Seller. These identifications may be incomplete and the quantities are estimates only. Seller is responsible for furnishing the items and quantities manifestly necessary to carry out the intent of the drawings and specifications.
(4) The drawings furnished by Company are, in general, to scale. Scales shown on a microfilmed reproduced drawing change in proportion to the reduction of the drawing from original size. Figured dimensions shall always be followed and the drawings not scaled.
(5) Prior to fabricating any item (structural steel, piping, ductwork, etc.) Seller shall field-verify all dimensions critical to the installation. Any discrepancies between existing or new conditions and the drawings shall be reported to Company for resolution.
(6...
Specifications and Drawings for Construction. (MAR 2019)
Specifications and Drawings for Construction. In accordance with FAR Clause 52.236-21 “Specifications and Drawings for Construction” (APR 1984), the Subcontractor shall keep a copy of the drawings and specifications on the work site and shall give project engineer access thereto. Anything mentioned in the specifications and not shown on the drawings or shown in the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In the case of difference between drawings and specifications, the specifications shall govern. In the case of discrepancy in the figures, in the drawings, or in the specifications, the specifications shall govern. In the case of a discrepancy in the figures, the matter shall be promptly submitted to project engineer who shall promptly make a determination in writing. Any adjustment by the Subcontractor without such a determination shall be at its own risk and expense. Chemonics shall furnish, from time to time, clarifications of detailed drawings and other information as considered necessary.
Specifications and Drawings for Construction. (MAR 2019) The requirements of the clause entitled “Specifications and Drawings for Construction” at FAR 52.236-21, are supplemented as follows:
Specifications and Drawings for Construction. A. The Contractor will keep on the Work site a copy of the drawings and specifications and will at all times give the City access thereto. Anything mentioned in the Work Specifications and not shown on the drawings, or shown on the drawings and not mentioned in the Work Specifications, will be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the Work Specifications will govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter will be promptly submitted to the City, who will promptly make a determination in writing which will be binding on the Contractor. Any adjustment by the Contractor without City’s written authorization will be at its own risk and expense. The City will furnish from time to time such detailed drawings and other information as considered necessary, unless otherwise provided.
B. If the Contract Documents require Shop Drawings, the Contractor will coordinate all such drawings, and review them for accuracy, completeness, and compliance with other requirements and will indicate its approval thereon as evidence of such coordination and review. Shop drawings submitted to the City without evidence of the Contractor's approval may be returned for resubmission. The City will indicate an approval or disapproval of the Shop Drawings and if not approved as submitted will indicate the Owner's reasons therefore. Any Work done before such approval will be at the Contractor's risk. Approval by the City will not relieve the Contractor from responsibility for any errors or omissions in such drawings, nor from responsibility for complying with the requirements under the Contract Documents.
C. It will be the responsibility of the Contractor to make timely requests for such large scale and full size drawings, color schemes, and other additional information, not already in his possession, which will be required in the planning and production of the Work. Such requests may be submitted as the need arises, but each such request will be filed in ample time to permit appropriate action to be taken by all Parties involved so as to avoid delay.
D. After approval of the shop drawings, the Contractor will submit three (3) copies (unless otherwise indicated) of all Shop Drawings as called for under the various headings of the specifications. One (1) set (unless otherwise indicated) of all Shop Drawings will be retained by the Owner, one will be retained by the City a...
Specifications and Drawings for Construction. The Donor shall keep on the work site a copy of the drawings and specifications and shall at all times give GSA and CBP access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of differences between drawings and specifications, the specifications shall govern. In case of discrepancies in the figures, in the drawings, or in the specifications, the matter shall be promptly submitted to GSA and CBP, who shall promptly make a determination in writing. Any adjustment by the Donor without such a determination shall be at its own risk and expense. If this project requires shop drawings, such as drawings on the mechanical and electrical work, such drawings must be submitted to the GSA Team Manager and CBP Project Manager for approval prior to work.