SUBMITTALS AND APPROVALS Sample Clauses

POPULAR SAMPLE Copied 1 times
SUBMITTALS AND APPROVALS. There is a formal process for the creation, review and approval of signage throughout The Carmel Center project. Prior to sign fabrication, plans for all proposed signage shall be submitted to the Owner who will review plans for conformance with the Sign Guidelines and Criteria. All plans submitted for approval must conform to requirements of the criteria contained in The Carmel Center Sign Guidelines and Criteria. Only those sign types specifically approved in writing by the Owner will be allowed. The Owner shall have the discretionary authority to deny approval for any submittal which does not comply with the intent or purpose of the sign criteria. The Tenant shall submit all sign designs to Owner and obtain his written approval prior to sign fabrication. Approval or disapproval shall remain the sole right and discretion of the Owner. The Tenant must continue to revise and resubmit rejected designs until approval is obtained. Prior to sign fabrication, the Tenant or his sign contractor shall submit for Owner approval three (3) sets of complete and fully-dimensioned shop drawings reflecting the sign design approved by the Owner. The shop drawings submittal shall include:
View SourceView Similar (5)
SUBMITTALS AND APPROVALS. A. Subcontractor shall carefully examine Specification requirements for approval material to be submitted such as shop drawings, data, schedules, samples, and other Documents as may be required. Then Subcontractor shall submit such material at its own expense and in such form as required by the Prime Contract t in sufficient time to prevent any delay in the delivery of such materials and the installation thereof. If “in place” or “as-built” drawings are specified to be prepared, these shall be prepared and submitted to Contractor before Final Payment is requested. B. Subcontractor shall submit, as a minimum, one (1) sepia and eight (8) prints of all shop drawings for approval and one (1) sepia and five (5) prints of approved shop drawings for field use. C. Subcontractor shall submit a list of Suppliers and Sub-subcontractors, if any, which it intends to use for the completion of its work under this Contract within ten
View SourceView Similar (2)
SUBMITTALS AND APPROVALS. A. Subcontractor shall carefully examine Specifications requirements for approval material to submit such as shop drawings, data, schedules, samples, and other documents as may be required and any other things or matters the subcontractor did or should have received. Then Subcontractor shall submit such materials at its own expense and in such form as required by the Prime Contract in sufficient time to prevent delay in the delivery of such materials and the installation thereof. If “in place” or “as built” drawings are specified to be prepared, these shall be prepared and submitted to Contractor before Final Payment is requested. B. Subcontractor, upon request shall submit as a minimum, One (1) sepia and Eight (8) prints of all shop drawings for approval and (1) sepia and Five (5) prints of approved shop drawings for field use. C. Subcontractor, upon request shall submit a list of Suppliers and Subcontractors, if any which it intends to use for the completion of its work under this contract within five (5) days from the date for any particular sublet of work is signed. Submitted Suppliers and/or Subcontractors shall be creditworthy and fully capable of timely performance. If in the sole judgment of Contractor, that one or more of the submitted Suppliers and/or Sub-subcontractors is unacceptable, Contractor shall notify Subcontractors of its decision, and Subcontractor shall procure replacement Suppliers and/or Sub- subcontractors for the Contractors approval within five (5) days from the date of Contractor’s notice . Such approval shall not be unreasonably withheld.
View Source
SUBMITTALS AND APPROVALS. Various submittals are required by Buyer pursuant to the Agreement. As expressly provided by this Agreement, City shall approve or disapprove certain submittals from Buyer within specified timeframes or else such submittal shall be deemed disapproved by the City. (SIGNATURE PAGE TO FOLLOW)
View Source
SUBMITTALS AND APPROVALS. Prior to sign fabrication. Tenant or occupant shall prepare shop drawings of all proposed exterior signs and submit three (3) sets to sheaProperties for review. Approvals provided by SheaProperties shall not Constitute County of Orange approval or guarantee jurisdictional approval. All sign plans and shop drawings must be approved by SheaProperties prior to submitting to the County of Orange. Shop drawings shall (Illegible) the following. 1.4.1. Tenant or its representative shall prepare shop drawings including: building elevation(s) illustrating sign location drawn to scale, a material board consisting of color & material samples, and specifications for fabrication including, but not limited to, gauge of material, paint manufacturer, method of attachment, and illumination requirements. 1.4.2. Upon receipt of the approved shop drawings from SheaProparties Tenant shall submit plans to the County of Orange for sign building permit. Changes or modifications required by the County of Orange must be reviewed by SheaProperties. 1.4.3. Scheduling of sign installation shall be coordinated with SheaProperties. No signs shall be installed prior to approval by SheaProperties. The Tenant is responsible for providing copies of the sign/building permit from the County of Orange, and a certificate of liability insurance naming SheaProperties as an additional insured for liability coverage, prior to schedulion any sign installation. 1.4.4. SheaProperties reserves the right to modify this sign (Illegible) consistent with the Aliso Viejo Town Center Sign Guidelines. SIGN PLAN TOWN CENTER CORPORATE PARK (ILLEGIBLE) TOWN CENTER SIGN PLAN CORPORATE PARK
View Source
SUBMITTALS AND APPROVALS. Contractor shall deliver to Owner copies of shop drawings, cuts, samples, material lists, and other submissions required by the Contract Documents (“Submittals”) within sufficient time so as not to delay performance of the Project. Submittals shall be in strict accordance with the Contract Documents; provided, however, if Contractor wishes to propose a deviation from the Contract Documents, such deviation shall be clearly identified on the Submittal and accompanied by a letter describing such deviation in detail and the effect, if any, on the Work and Contractor’s time of performance. Requested deviations will be allowed only when express written approval referencing the specific deviation is given by Owner to Contractor. No general approval granted by Owner shall relieve Contractor from complying with the Contract Documents. Owner’s review of Submittals shall not be construed as a complete check or approval of such documents nor shall it relieve Contractor from responsibility for errors of any sort in Submittals, or from the necessity of furnishing any Work required by the Contract Documents which may have been omitted from any Submittal. In addition, upon Contractor’s completion of the Work, Contractor shall provide a written or graphic record of as-built conditions of the Work, such as marked-up blueline prints or the like, to Owner’s architectural and engineering consultants working on the Project. Receipt of the as-built drawings by the consultants and confirmation of such receipt by Owner is a condition precedent to final payment to Contractor under this Contract.
View Source
SUBMITTALS AND APPROVALS. Submittals and shop drawings submitted to the Architect by the Construction Manager shall be returned, approved or disapproved, within fourteen (14) working days after the Architect’s receipt of the same. The Construction Manager is responsible to maintain the proper flow of submittals for approval through the Architect’s office to avoid any project delays. The Construction Manager shall submit or resubmit materials, drawings or other data promptly to the Architect or Engineer to avoid delays.
View Source
SUBMITTALS AND APPROVALS 
View SourceView Similar (5)

Related to SUBMITTALS AND APPROVALS

  • Permits and Approvals Consultant shall obtain, at its sole cost and expense, all permits and regulatory approvals necessary in the performance of this Agreement. This includes, but shall not be limited to, encroachment permits and building and safety permits and inspections.

  • Regulatory Consents and Approvals All consents, approvals and actions of, filings with and notices to any Governmental or Regulatory Authority necessary to permit Purchaser and Seller to perform their obligations under this Agreement and the Operative Agreements and to consummate the transactions contemplated hereby and thereby (a) shall have been duly obtained, made or given, (b) shall be in form and substance reasonably satisfactory to Purchaser, (c) shall not be subject to the satisfaction of any condition that has not been satisfied or waived and (d) shall be in full force and effect, and all terminations or expirations of waiting periods imposed by any Governmental or Regulatory Authority necessary for the consummation of the transactions contemplated by this Agreement and the Operative Agreements shall have occurred.

  • Licenses and Approvals Contractor shall obtain and keep current all necessary licenses, approvals, permits and authorizations required by Applicable Laws to provide the Work. Contractor will be responsible for all fees and taxes associated with obtaining such licenses, approvals, permits and authorizations, and for any fines and penalties arising from its noncompliance with any Applicable Law.

  • Authorizations and Approvals Each Borrower shall promptly obtain, from time to time at its own expense, all such Governmental Approvals as may be required to enable such Borrower to comply with its obligations, under the Loan Documents and its Constituent Documents, and to conduct its business in the customary fashion.

  • Approvals and Filings (a) Upon the terms and subject to the conditions set forth in this Agreement, each of FSC and ABCB agrees to use its reasonable best efforts to take, or cause to be taken, all actions and to do, or cause to be done, and to assist and cooperate with the other party in doing, all things necessary, proper or advisable to fulfill all conditions applicable to such party and its respective Subsidiaries pursuant to this Agreement and the Bank Merger Agreement and to consummate and make effective, in the most expeditious manner practicable, the transactions contemplated by this Agreement and the Bank Merger Agreement, including: (i) obtaining all Regulatory Approvals and all other necessary, proper or advisable actions or non-actions, waivers, consents, qualifications and approvals from Governmental Authorities and making all necessary, proper or advisable registrations, filings and notices and taking all steps as may be necessary to obtain an approval, waiver or exemption from any Governmental Authority; provided, however, that nothing contained herein shall be deemed to require ABCB, or require or permit FSC, to take any action, or commit to take any action, or agree to any condition or restriction, in connection with obtaining the permits, consents, approvals and authorizations of any Governmental Authority that would reasonably be expected to have a material adverse effect (measured on a scale relative to FSC and its Subsidiaries taken as a whole) on the Surviving Corporation and its Subsidiaries, after giving effect to the Merger (a “Materially Burdensome Regulatory Condition”); (ii) obtaining all necessary, proper or advisable consents, qualifications, approvals, waivers or exemptions from nongovernmental Persons; and (iii) executing and delivering any additional documents or instruments necessary, proper or advisable to consummate the transactions contemplated by, and to fully carry out the purposes of, this Agreement or the Bank Merger Agreement. (b) Without limiting the generality of the foregoing, ABCB and FSC shall make any required filings of applications, filings and notices with the Federal Reserve Board, the FDIC and the GDBF in connection with the Merger or the Bank Merger within forty-five (45) days after the date of this Agreement and shall each use, and shall cause their applicable Subsidiaries to use, reasonable best efforts to prepare and file any applications, notices and filings required in order to obtain the Regulatory Approvals as promptly as practicable after the date of this Agreement. ABCB and FSC shall each use, and shall each cause their applicable Subsidiaries to use, reasonable best efforts to obtain each such approval as promptly as reasonably practicable. The parties shall cooperate with each other in connection therewith (including the furnishing of any information and any reasonable undertaking or commitments that may be required to obtain the Regulatory Approvals). Each party will provide the other with copies of (i) any applications and all correspondence relating thereto prior to filing, other than material filed in connection therewith under a claim of confidentiality, and (ii) copies of correspondence from all Regulatory Agencies. (c) Subject to Applicable Law (including Applicable Law relating to the exchange of information), the parties shall advise each other promptly after receiving any communication from any Governmental Authority whose consent or approval is required for consummation of the transactions contemplated by this Agreement or by the Bank Merger Agreement that causes such party to believe that there is a reasonable likelihood that the Regulatory Approvals or any other consent or approval required hereunder will not be obtained or that the receipt of any such approval will be materially delayed.