ARCHITECTURAL AND CONSTRUCTION PROCEDURES Clause Samples

ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Landlord shall pay up to the amount of the “Landlord’s Contribution” (as defined below) towards the cost of the Tenant Improvement Work. Any additional cost of the Tenant Improvement Work, including additional costs resulting from “Changes” (as hereinafter defined) requested by Tenant, shall be borne solely by Tenant and paid to Landlord as hereinafter provided. Unless otherwise specified in the Plan or Cost Estimate, all materials, specifications and finishes utilized in constructing the Tenant Improvements shall be Landlord’s building standard tenant improvements, materials and specifications for the Project as set forth in Schedule I attached hereto (“Standard Improvements”). Should Landlord submit any additional plans, equipment specification sheets, or other matters to Tenant for approval or completion in connection with the Tenant Improvement Work, Tenant shall respond in writing, as appropriate, within 5 days unless a shorter period is provided herein. Tenant shall not unreasonably withhold its approval of any matter, and any disapproval shall be limited to items not previously approved by Tenant in the Plan or otherwise. B. In the event that Tenant requests in writing a revision to the Plan (“Change”), and Landlord so approves such Change as provided in Section 1.C below, Landlord shall advise Tenant by written change order as soon as is practical of any increase in the cost to complete the Tenant Improvement Work that such Change would cause. Such cost of the Change shall include an administrative/supervision fee to be paid to Landlord or to Landlord’s management agent in the amount of 5% of the cost of such Change. Tenant shall approve or disapprove such change order in writing within 2 days following Tenant’s receipt of such change order. If Tenant approves any such change order, Landlord, at its election, may either (i) require as a condition to the effectiveness of such change order that Tenant pay the increase in the cost to complete attributable to such change order concurrently with delivery of Tenant’s approval of the change order, or (ii) defer Tenant’s payment of such increase until the date 10 days after delivery of invoices for same. If Tenant disapproves any such change order, Tenant shall nonetheless be responsible for the reasonable architectural and/or planning fees incurred in preparing such change order. Landlord shall have no obligation to interrupt or modify the Tenant Improvement Work pending Tenant’s approval of a change o...
View SourceView Similar (65)
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Prior to the execution of this Lease, Tenant and Landlord have approved a detailed plan for the Tenant Improvements prepared by ▇. ▇▇▇▇▇ Associates, dated December 16, 2014 (“Preliminary Plan”), and (ii) an estimate prepared by Casco Contractors, dated January 5, 2014 of the cost to complete the Tenant Improvements in accordance with the Preliminary Plan (“Preliminary Cost Estimate”). To the extent applicable, the build-out of the Tenant Improvements shall include Landlord’s building standard tenant improvements, materials and specifications for the Project (“Building Standard Improvements”), except for those additions or variations to Building Standard Improvements expressly approved by Landlord and noted on the Preliminary Plan (any such addition or variation from the Standard Improvements shall be referred to herein as a “Non-Standard Improvement”) B. Within 5 business days following any request from Landlord or Landlord’s architect, Tenant shall provide in writing to Landlord or Landlord's architect all specifications and information requested by Landlord for the preparation of final construction documents and costing, including without limitation Tenant's final selection of paint and floor finishes, complete specifications and locations (including electrical, load and HVAC requirements) of Tenant's equipment, and details of all Non-Standard Improvements (as defined above) which have been approved by Landlord as part of the Preliminary Plan (collectively, "Programming Information"). Tenant understands that final construction documents for the Tenant Improvements shall be predicated on the Programming Information, and accordingly that such information must be accurate and complete and that any defects or problems due to incomplete or inaccurate Programming Information shall be the responsibility of the Tenant and that the Landlord shall have no obligation or liability for such defects or problems arising from any incomplete or inaccurate Programming Information. C. Following receipt of the Programming Information, Landlord's architect and engineers shall prepare and deliver to Tenant working drawings and specifications for the Tenant Improvements based on the approved Preliminary Plan ("Working Drawings and Specifications"), and Landlord's contractor shall prepare a final construction cost estimate ("Final Cost Estimate") for the Tenant Improvements in conformity with the Working Drawings and Specifications. Tenant shall have 5 business days from the...
View SourceView Similar (6)
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Landlord shall cause its contractor to construct the Tenant Improvements at Landlord’s sole cost and expense, provided that any additional cost resulting from “Changes” (as hereinafter defined) requested by Tenant and “Alternates” shown in the Plan which are elected by Tenant (if any) shall be borne solely by Tenant and paid to Landlord as hereinafter provided. Unless otherwise specified in the Plan, all materials, specifications and finishes utilized in constructing the Tenant Improvements shall be Landlord’s building standard tenant improvements, materials and specifications for the Project (“Standard Improvements”), except for those additions or variations to Building Standard Improvements expressly approved by Landlord and noted on the Plan (any such addition or variation from the Standard Improvements shall be referred to herein as a “Non-Standard Improvement”). Should Landlord submit any additional plans, equipment specification sheets, or other matters to Tenant for approval or completion in connection with the Tenant Improvement Work, Tenant shall respond in writing, as appropriate, within 5 business days unless a shorter period is provided herein. Tenant shall not unreasonably withhold its approval of any matter, and any disapproval shall be limited to items not previously approved by Tenant in the Plan or otherwise.
View SourceView Similar (2)
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Concurrently with sign-off by Tenant, the space plans, construction drawings and specifications for all improvements and finishes, together with any changes thereto, shall be submitted to Landlord (with samples as required) for review and approval by Landlord and its architect for the Project. To the extent applicable, the build-out of the Tenant Improvements shall include Landlord’s building standard tenant improvements, materials and specifications for the Project. Should Landlord approve work that would necessitate any ancillary Building modification or other expenditure by Landlord, then except to the extent of any remaining balance of the “Landlord Contribution” as described below, Tenant shall, in addition to its other obligations herein, promptly fund the cost thereof to Landlord.
View Source
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Tenant shall engage Design Blitz for the preparation of a detailed space plan for the Premises which includes interior partitions, ceilings, interior finishes, interior office doors, suite entrance, floor coverings, window coverings, lighting, electrical and telephone outlets, plumbing connections, heavy floor loads and other special requirements (“Preliminary Plan”). Upon completion of the Preliminary Plan, Landlord and Tenant shall approve an estimate of the cost to complete the Tenant Improvements in accordance with the Preliminary Plan (“Preliminary Cost Estimate”), which Preliminary Cost Estimate will be based upon estimated costs provided by Landlord’s contractor. To the extent applicable, the Preliminary Plan shall include Landlord’s building standard tenant improvements, materials and specifications for the Project as set forth in Schedule I attached hereto (“Standard Improvements”), except for changes and additions specifically requested by Tenant and approved by Landlord in writing (any such addition or variation from the Standard Improvements shall be referred to herein as a “Non-Standard Improvement”). In all events, Tenant shall approve in all respects a Preliminary Plan and a Preliminary Cost Estimate for the 43 Discovery Premises not later than May 31, 2018 (“Plan Approval Date”), it being understood that Tenant’s failure to do so shall constitute a “Tenant Delay” (as defined below).
View Source
ARCHITECTURAL AND CONSTRUCTION PROCEDURES. A. Landlord shall cause its contractor to construct the Tenant Improvements shown on the Plan at Landlord's sole cost and expense. In addition, Landlord shall pay up to the amount of the "Landlord's Contribution" (as defined below) towards any additional cost resulting from a "Change" (as hereinafter defined) requested by Tenant. Unless otherwise specified in the Plan or in any Change approved by Landlord, all materials, specifications and finishes utilized in constructing the Tenant Improvements shall be Landlord's building standard tenant improvements, materials and specifications for the Project ("STANDARD IMPROVEMENTS"). Should Landlord submit any additional plans, equipment specification sheets, or other matters to Tenant for approval or completion in connection with the Tenant Improvement Work, Tenant shall respond in writing, as appropriate, within five (5) days unless a shorter period is provided herein. Tenant shall not unreasonably withhold its approval of any matter, and any disapproval shall be limited to items not previously approved by Tenant in the Plan or otherwise.
View Source
ARCHITECTURAL AND CONSTRUCTION PROCEDURES 
View Source

Related to ARCHITECTURAL AND CONSTRUCTION PROCEDURES

  • SUPERVISION AND CONSTRUCTION PROCEDURES 4.3.1 The Contractor shall supervise and direct the Work, using his / her best skill and attention. The Contractor shall be solely responsible for all construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under the Contract. All aspects of the Project shall be subject to the inspection and approval of the State. Contractor guarantees to repair, replace, re-execute or otherwise correct any defect in workmanship, materials, or the like that fails to conform to the requirements of this Contract or that appears during the progress of the Work or within one year of final acceptance by the State. 4.3.2 The Contractor shall be responsible to the State for the acts and omissions of his / her employees, Subcontractors and their agents and employees, and other persons performing any of the Work under a contract with the Contractor. 4.3.3 The Contractor shall not be relieved from his / her obligations to perform the Work in accordance with the Contract Documents either by the activities or duties of the Architect in his / her administration of the Contract, or by inspections, tests or approvals required or performed under Paragraph 7.7 by persons other than the Contractor. 4.3.4 The Contractor shall acquaint himself (herself / itself) with the limits of the property or right- of-way of the State and shall not trespass on other property. The Contractor shall adequately protect the project, adjacent property and the public, and shall be responsible for any damage or injury due to the Contractor’s act or neglect, and shall save the State harmless in respect thereto. 4.3.5 All work shall be done in such a manner as not to interfere with the State’s operating functions. Contractor and his employees shall familiarize themselves and comply with all rules and regulations applicable to the project. 4.3.6 The Contractor shall keep the premises free from liens arising out of or from the Project. Contractor shall obtain and submit waivers of liens with a request for a progress or final payment.

  • Review and Construction of Documents Each Party herein expressly represents and warrants to all other Parties hereto that (a) before executing this Agreement, said Party has fully informed itself of the terms, contents, conditions and effects of this Agreement; (b) said Party has relied solely and completely upon its own judgment in executing this Agreement; (c) said Party has had the opportunity to seek and has obtained the advice of its own legal, tax and business advisors before executing this Agreement; (d) said Party has acted voluntarily and of its own free will in executing this Agreement; and (e) this Agreement is the result of arm’s length negotiations conducted by and among the Parties and their respective counsel.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Design and Construction In complying with the requirements of the specification both with respect to arrangement and detail, design is to conform to the best current engineering practice. Each of the several parts of the material is to be of the maker’s standard design provided that this design is in general accordance with the specification. The essence of design should be simplicity and reliability in order to give long continuous service with high economy and low maintenance cost. Particular attention should be paid to internal and external access in order to facilitate inspection, cleaning and maintenance. The design dimensions and materials of all parts are to be such that they will not suffer damage as a result of stresses under the most severe conditions. Fully detailed specifications of the several parts of the material are to be submitted describing particularly the materials to be used. The materials used in the construction of the material are to be of the highest quality and selected particularly to meet the duties required of them. Mechanisms are to be constructed to avoid sticking due to rust or corrosion. Workmanship and general finish are to be of the highest class throughout. All similar parts of the material are to be interchangeable. All equipment is to operate without undue vibration and with the least possible amount of noise and is not to cause a nuisance. All equipment is to be designed to minimize the risk of fire and any damage, which may be caused in the event of fire. The equipment is also to be designed to prevent ingress of all vermin, accidental contact with live parts and to minimize the ingress of dust and dirt. The use of materials, which may be liable to attack by termites or other insects, is to be avoided.